Form 10-Q for Period Ended June 30, 2004

 

FORM 10-Q
 
UNITED STATES SECURITIES AND EXCHANGE COMMISSION
Washington, D.C. 20549
 
 
[X] Quarterly Report Pursuant to Section 13 or 15(d) of the
Securities Exchange Act of 1934
For the quarterly period ended June 30, 2004
 
OR
 
[ ] Transition Report Pursuant to Section 13 or 15(d)
of the Securities Exchange Act of 1934
For the transition period from _____ to _____
 
 
 
Commission File Number 1-3492
 
 
HALLIBURTON COMPANY
 
(a Delaware Corporation)
75-2677995
 
5 Houston Center
1401 McKinney, Suite 2400
Houston, Texas 77010
(Address of Principal Executive Offices)
 
Telephone Number - Area Code (713) 759-2600
 
Indicate by check mark whether the registrant (1) has filed all reports required to be filed by Section 13 or 15(d) of the Securities Exchange Act of 1934 during the preceding 12 months (or for such shorter period that the registrant was required to file such reports), and (2) has been subject to such filing requirements for the past 90 days.
Yes X No ___

 
Indicate by check mark whether the registrant is an accelerated filer (as defined in Rule 12b-2 of the Act).
Yes X No ___

 
As of July 23, 2004, 441,529,147 shares of Halliburton Company common stock, $2.50 par value per share, were outstanding.


     



 
HALLIBURTON COMPANY
 
 
 
 
 
Index
 
 
 
 
 
 
Page No.

PART I.
FINANCIAL INFORMATION
 
 
 
 
Item 1.
Financial Statements
3-33
 
 
 
 
-   Condensed Consolidated Statements of Operations
3
 
-   Condensed Consolidated Balance Sheets
4
 
-   Condensed Consolidated Statements of Cash Flows
5
 
-   Notes to Condensed Consolidated Financial Statements
6-33
 
 
 
Item 2.
Management’s Discussion and Analysis of Financial Condition and
 
 
Results of Operations
34-73
 
 
 
Item 3.
Quantitative and Qualitative Disclosures about Market Risk
74
 
 
 
Item 4.
Controls and Procedures
74
 
 
 
PART II.
OTHER INFORMATION
 
 
 
 
Item 1.
Legal Proceedings
75
 
 
 
Item 2.
Changes in Securities, Use of Proceeds, and Issuer Purchases of
 
 
Equity Securities
75
 
 
 
Item 3.
Defaults Upon Senior Securities
75
 
 
 
Item 4.
Submission of Matters to a Vote of Security Holders
75-76
 
 
 
Item 5.
Other Information
76
 
 
 
Item 6.
Exhibits and Reports on Form 8-K
77-79
 
 
 
Signatures
 
80

 
  2  

 
PART I. FINANCIAL INFORMATION
Item 1. Financial Statements
HALLIBURTON COMPANY
Condensed Consolidated Statements of Operations
(Unaudited)
(Millions of dollars and shares except per share data)

 
 
Three Months
Six Months
 
 
Ended June 30
Ended June 30
   

 
 
2004
2003
2004
2003

 
 
 
 
 
Revenues:
   
 
   
 
   
 
   
 
 
Services
 
$
4,448
 
$
3,106
 
$
9,484
 
$
5,735
 
Product sales
   
515
   
476
   
1,006
   
924
 
Equity in earnings (losses) of unconsolidated affiliates
   
(7
)
 
17
   
(15
)
 
-
 

 
 
 
 
 
Total revenues
   
4,956
   
3,599
   
10,475
   
6,659
 

 
 
 
 
 
Operating costs and expenses:
   
 
   
 
   
 
   
 
 
Cost of services
   
4,442
   
3,050
   
9,237
   
5,504
 
Cost of sales
   
462
   
425
   
915
   
829
 
General and administrative
   
78
   
80
   
174
   
161
 
Gain on sale of business assets, net
   
-
   
(27
)
 
-
   
(48
)

 
 
 
 
 
Total operating costs and expenses
   
4,982
   
3,528
   
10,326
   
6,446
 

 
 
 
 
 
Operating income (loss)
   
(26
)
 
71
   
149
   
213
 
Interest expense
   
(53
)
 
(25
)
 
(109
)
 
(52
)
Interest income
   
7
   
7
   
17
   
15
 
Foreign currency gains (losses), net
   
(7
)
 
19
   
(10
)
 
13
 
Other, net
   
(1
)
 
2
   
4
   
2
 
Income (loss) from continuing operations before income
   
 
   
 
   
 
   
 
 
taxes, minority interest, and change in accounting
   
 
   
 
   
 
   
 
 
principle
   
(80
)
 
74
   
51
   
191
 
(Provision) benefit for income taxes
   
29
   
(29
)
 
(20
)
 
(79
)
Minority interest in net income of subsidiaries
   
(7
)
 
(3
)
 
(13
)
 
(11
)

 
 
 
 
 
Income (loss) from continuing operations before change
   
 
   
 
   
 
   
 
 
in accounting principle
   
(58
)
 
42
   
18
   
101
 
Loss from discontinued operations, net of tax
   
 
   
 
   
 
   
 
 
benefit of $87, $26, $146 and $30
   
(609
)
 
(16
)
 
(750
)
 
(24
)
Cumulative effect of change in accounting principle,
   
 
   
 
   
 
   
 
 
net of tax benefit of $5
   
-
   
-
   
-
   
(8
)

 
 
 
 
 
Net income (loss)
 
$
(667
)
$
26
 
$
(732
)
$
69
 

 
 
 
 
 
Basic income (loss) per share:
   
 
   
 
   
 
   
 
 
Income (loss) from continuing operations before change in
   
 
   
 
   
 
   
 
 
accounting principle
 
$
(0.13
)
$
0.09
 
$
0.04
 
$
0.23
 
Loss from discontinued operations, net
   
(1.39
)
 
(0.03
)
 
(1.71
)
 
(0.05
)
Cumulative effect of change in accounting principle, net
   
   -
   
   -
   
-
   
(0.02
)

 
 
 
 
 
Net income (loss)
 
$
(1.52
)
$
0.06
 
$
(1.67
)
$
0.16
 

 
 
 
 
 
Diluted income (loss) per share:
   
 
   
 
   
 
   
 
 
Income (loss) from continuing operations before change in
   
 
   
 
   
 
   
 
 
accounting principle
 
$
(0.13
)
$
0.09
 
$
0.04
 
$
0.23
 
Loss from discontinued operations, net
   
(1.39
)
 
(0.03
)
 
(1.71
)
 
(0.05
)
Cumulative effect of change in accounting principle, net
   
   -
   
   -
   
-
   
(0.02
)

 
 
 
 
 
Net income (loss)
 
$
(1.52
)
$
0.06
 
$
(1.67
)
$
0.16
 

 
 
 
 
 
 
   
 
   
 
   
 
   
 
 
Cash dividends per share
 
$
0.125
 
$
0.125
 
$
0.25
 
$
0.25
 
Basic weighted average common shares outstanding
   
437
   
   434
   
   437
   
434
 
Diluted weighted average common shares outstanding
   
437
   
   436
   
   440
   
436
 

See notes to condensed consolidated financial statements.
 
  3  

 
HALLIBURTON COMPANY
Condensed Consolidated Balance Sheets
(Unaudited)
(Millions of dollars and shares except per share data)
 
 
June 30
December 31
 
 
2004
2003

 
 
 
Assets
   
 
   
 
 
Current assets:
   
 
   
 
 
Cash and equivalents
 
$
2,230
 
$
1,815
 
Receivables:
   
 
   
 
 
Notes and accounts receivable
   
3,223
   
2,909
 
Unbilled work on uncompleted contracts
   
1,572
   
1,760
 
Insurance for asbestos- and silica-related liabilities
   
981
   
96
 

 
 
 
Total receivables
   
5,776
   
4,765
 
Inventories
   
741
   
695
 
Current deferred income taxes
   
273
   
188
 
Other current assets
   
511
   
456
 

 
 
 
Total current assets
   
9,531
   
7,919
 
Property, plant, and equipment, net of accumulated depreciation of $3,624 and $3,540
   
2,564
   
2,526
 
Goodwill
   
793
   
670
 
Noncurrent deferred income taxes
   
774
   
738
 
Equity in and advances to related companies
   
476
   
579
 
Insurance for asbestos- and silica-related liabilities
   
468
   
2,038
 
Other assets
   
913
   
993
 

 
 
 
Total assets
 
$
15,519
 
$
15,463
 

 
 
 
Liabilities and Shareholders’ Equity
   
 
   
 
 
Current liabilities:
   
 
   
 
 
Asbestos- and silica-related liabilities
 
$
2,399
 
$
2,507
 
Accounts payable
   
2,087
   
1,776
 
Advance billings on uncompleted contracts
   
747
   
741
 
Accrued employee compensation and benefits
   
482
   
400
 
Reserve for estimated loss on uncompleted contracts
   
403
   
225
 
Income taxes payable
   
116
   
236
 
Deferred revenues
   
101
   
104
 
Current maturities of long-term debt
   
50
   
22
 
Other current liabilities
   
448
   
531
 

 
 
 
Total current liabilities
   
6,833
   
6,542
 
Long-term debt
   
3,900
   
3,415
 
Asbestos- and silica-related liabilities
   
1,754
   
1,579
 
Employee compensation and benefits
   
787
   
801
 
Other liabilities
   
393
   
479
 

 
 
 
Total liabilities
   
13,667
   
12,816
 

 
 
 
Minority interest in consolidated subsidiaries
   
116
   
100
 
Shareholders’ equity:
   
 
   
 
 
Common shares, par value $2.50 per share – authorized 1,000 and 600 shares,
   
 
   
 
 
issued 457
   
1,143
   
1,142
 
Paid-in capital in excess of par value
   
267
   
273
 
Deferred compensation
   
(81
)
 
(64
)
Accumulated other comprehensive income
   
(307
)
 
(298
)
Retained earnings
   
1,229
   
2,071
 

 
 
 
 
   
2,251
   
3,124
 
Less 17 and 18 shares of treasury stock, at cost
   
515
   
577
 

 
 
 
Total shareholders’ equity
   
1,736
   
2,547
 

 
 
 
Total liabilities and shareholders’ equity
 
$
15,519
 
$
15,463
 

 
 
 

See notes to condensed consolidated financial statements.
 
  4  

 
HALLIBURTON COMPANY
Condensed Consolidated Statements of Cash Flows
(Unaudited)
(Millions of dollars)
 
 
Six Months
 
 
Ended June 30
   
 
 
2004
2003

 
 
 
Cash flows from operating activities:
   
 
   
 
 
Net income (loss)
 
$
(732
)
$
69
 
Adjustments to reconcile net income (loss) to net cash from operations:
   
 
   
 
 
Loss from discontinued operations
   
750
   
24
 
Depreciation, depletion and amortization
   
256
   
252
 
Provision (benefit) for deferred income taxes, including $(107) and
   
 
   
 
 
$(8) related to discontinued operations
   
(120
)
 
(77
)
Distributions from (advances to) related companies, net of
   
 
   
 
 
equity in (earnings) losses
   
(3
)
 
47
 
Change in accounting principle, net
   
-
   
8
 
Gain on sale of assets, net
   
(6
)
 
(53
)
Other non-cash items
   
9
   
(35
)
Other changes:
   
 
   
 
 
Total receivables
   
(492
)
 
(417
)
Proceeds from sale of accounts receivable
   
318
   
-
 
Inventories
   
(31
)
 
(45
)
Accounts payable
   
282
   
(50
)
Restricted cash related to Chapter 11 proceedings
   
(112
)
 
-
 
Other working capital, net
   
44
   
139
 
Other operating activities
   
17
   
(75
)

 
 
 
Total cash flows from operating activities
   
180
   
(213
)

 
 
 
Cash flows from investing activities:
   
 
   
 
 
Capital expenditures
   
(284
)
 
(229
)
Sales of property, plant, and equipment
   
57
   
49
 
Dispositions (acquisitions) of businesses, net of
   
 
   
 
 
cash disposed (acquired)
   
(22
)
 
224
 
Proceeds from sale of securities
   
20
   
57
 
Investments – restricted cash
   
88
   
(22
)
Other investing activities
   
(10
)
 
(29
)

 
 
 
Total cash flows from investing activities
   
(151
)
 
50
 

 
 
 
Cash flows from financing activities:
   
 
   
 
 
Proceeds from long-term borrowings, net of offering costs
   
496
   
1,178
 
Payments on long-term borrowings
   
(11
)
 
(140
)
Borrowings (repayments) of short-term debt, net
   
(7
)
 
(34
)
Payments of dividends to shareholders
   
(110
)
 
(109
)
Payments to reacquire common stock
   
(5
)
 
(5
)
Proceeds from exercises of stock options
   
23
   
9
 
Other financing activities
   
(1
)
 
(6
)

 
 
 
Total cash flows from financing activities
   
385
   
893
 

 
 
 
Effect of exchange rate changes on cash
   
1
   
22
 
Increase (decrease) in cash and equivalents
   
415
   
752
 
Cash and equivalents at beginning of period
   
1,815
   
1,107
 

 
 
 
Cash and equivalents at end of period
 
$
2,230
 
$
1,859
 

 
 
 
 
   
 
   
 
 
Supplemental disclosure of cash flow information:
   
 
   
 
 
Cash payments during the period for:
   
 
   
 
 
Interest
 
$
102
 
$
48
 
Income taxes
 
$
110
 
$
100
 

 
 
 
See notes to condensed consolidated financial statements.
 
  5  

 
HALLIBURTON COMPANY
Notes to Condensed Consolidated Financial Statements
(Unaudited)

Note 1. Basis of Presentation
The accompanying unaudited condensed consolidated financial statements were prepared using generally accepted accounting principles for interim financial information and the instructions to Form 10-Q and Regulation S-X. Accordingly, these financial statements do not include all information or footnotes required by generally accepted accounting principles for annual financial statements and should be read together with our 2003 Annual Report on Form 10-K, as amended. The condensed consolidated financial statements also include the accounts of all of our subsidiaries currently in Chapter 11 proceedings (see Note 13). Certain prior period amounts have been reclassified to be consistent with the current presentation.
Our accounting policies are in accordance with generally accepted accounting principles in the United States of America. The preparation of financial statements in conformity with these accounting principles requires us to make estimates and assumptions that affect:
   -   the reported amounts of assets and liabilities and disclosure of contingent assets and liabilities at the date of the financial statements; and
   -   the reported amounts of revenue and expenses during the reporting period.
Ultimate results could differ from our estimates.
In our opinion, the condensed consolidated financial statements included herein contain all adjustments necessary to present fairly our financial position as of June 30, 2004, the results of our operations for the three and six months ended June 30, 2004 and 2003 and our cash flows for the six months ended June 30, 2004 and 2003. Such adjustments are of a normal recurring nature. The results of operations for the six months ended June 30, 2004 and 2003 may not be indicative of results for the full year.

Note 2. Long-Term Construction Contracts
The amounts included in determining the profit or loss on contracts and the amounts recorded for the three and six months ended June 30, 2004 are as follows:

 
 
Total Probable Unapproved
Probable Unapproved Claims
 
 
Claims
Accrued Revenue
 
 
(included in determining
(unbilled work on
 
 
contract profit or loss)
uncompleted contracts)
   

 
 
Three Months
Six Months
Three Months
Six Months
 
 
Ended
Ended
Ended
Ended
(Millions of dollars)
 
June 30, 2004
June 30, 2004
June 30, 2004
June 30, 2004

 
 
 
 
 
Beginning balance
 
$
230
 
$
233
 
$
227
 
$
225
 
Additions
   
32
   
143
   
32
   
141
 
Costs incurred during period
   
-
   
-
   
2
   
3
 
Other
   
-
   
(114
)
 
-
   
(108
)

 
 
 
 
 
Ending Balance
 
$
262
 
$
262
 
$
261
 
$
261
 

 
 
 
 
 

The probable unapproved claims as of June 30, 2004 relate to eight contracts, most of which are complete or substantially complete. In addition, approximately 57% of these claims are with one customer. We are actively engaged in claims negotiations with our customers. The increase in the second quarter of 2004 of $32 million is primarily government-related activities for costs exceeding the funding value on a task order for the Restore Iraqi Oil I (RIO I) project. A formal claim was submitted to the client in late June 2004. The change in probable unapproved claims for the six months ended June 30, 2004 includes reaching an agreement in principle in April of 2004 with Petroleo Brasilero SA (Petrobras) that, if
 
  6  

 
implemented, would resolve outstanding issues regarding the Barracuda-Caratinga project (see Note 3). Implementation of the agreement in principle requires final approval of the Board of Directors of Petrobras and Halliburton, the project lenders, and the bankruptcy court of the Chapter 11 proceedings of Kellogg Brown & Root and certain other subsidiaries. The December 31, 2003 probable unapproved claims related to the Barracuda-Caratinga project of $114 million was reduced to $79 million and reclassified, in the first quarter of 2004, as an unapproved change order as a result of the agreement in principle. The change in probable unapproved claims in the six months ended June 30, 2004 also included a $76 million reclassification from unapproved change orders for two projects for a single customer who is disputing the pricing of previously agreed-upon scope changes.
There are probable unapproved claims that will likely not be settled within one year, totaling $206 million at June 30, 2004 and $204 million at December 31, 2003 included in the table above, which are reflected as “Other assets” on the condensed consolidated balance sheets. Other probable unapproved claims included in the table above have been recorded to “Unbilled work on uncompleted contracts” included in the “Total receivables” amount on the condensed consolidated balance sheets. In addition, we are negotiating change orders to the contract scope where we have agreed upon the scope of work but not the price. Including the $79 million related to the Barracuda-Caratinga project, these change orders amount to $95 million at June 30, 2004. Unapproved change orders at December 31, 2003 were $97 million.
Our unconsolidated related companies include probable unapproved claims as revenue to determine the amount of profit or loss for their contracts. Probable unapproved claims from our related companies are included in “Equity in and advances to related companies” and our share totaled $62 million at June 30, 2004 and $10 million at December 31, 2003. Over 70% of these claims at June 30, 2004 are with one customer. In addition, our unconsolidated related companies are negotiating change orders to the contract scope where we have agreed upon the scope of work but not the price. Our share of these change orders totaled $33 million at June 30, 2004 and $59 million at December 31, 2003.

Note 3. Barracuda-Caratinga Project
In June 2000, Kellogg Brown & Root, Inc. entered into a contract with Barracuda & Caratinga Leasing Company B.V., the project owner, to develop the Barracuda and Caratinga crude oilfields, which are located off the coast of Brazil. The construction manager and project owner's representative is Petrobras, the Brazilian national oil company. When completed, the project will consist of two converted supertankers, Barracuda and Caratinga, which will be used as floating production, storage, and offloading units, commonly referred to as FPSOs. In addition, there will be 32 hydrocarbon production wells, 22 water injection wells, and all subsea flow lines, umbilicals, and risers necessary to connect the underwater wells to the FPSOs. The original completion date for the Barracuda vessel was December 2003, and the original completion date for the Caratinga vessel was April 2004. The pr oject is significantly behind the original schedule, due in large part to change orders from the project owner, and is in a financial loss position. We expect that the Barracuda vessel will likely be completed by June 2005, and the Caratinga vessel will likely be completed by November 2005. However, there can be no assurance that further delays will not occur.
Our performance under the contract is secured by:
-   performance letters of credit, which together have available credit of approximately $272 million as of June 30, 2004 and represent approximately 10% of the contract amount, as amended to date by change orders;
-   retainage letters of credit, which together have available credit of approximately $170 million as of June 30, 2004 and which will increase in order to continue to represent 10% of the cumulative cash amounts paid to us; and
-   a guarantee of KBR’s performance under the agreement by Halliburton Company in favor of the project owner.
In early April 2004, KBR and Petrobras, on behalf of the project owner, entered into a nonbinding agreement in principle. The April 2004 agreement in principle is the basis for settlement of the various claims between the parties and would amend existing agreements. Implementation of the agreement in
 
  7  

 
principle requires final approval of the Board of Directors of Petrobras and Halliburton, the project lenders, and possibly the bankruptcy court that confirmed our proposed plan of reorganization. Discussions among all parties, including the project lenders, are underway. The April 2004 agreement in principle provides for:
-   the release of all claims of all parties that arise prior to the effective date of a final definitive agreement;
-   the payment to us of $79 million as a result of change orders for remaining claims;
-   payment by Petrobras of any value added taxes on the project, except for $8 million which has been paid by us;
-   the assumption by Petrobras of certain work under the original contract;
-   the repayment on December 7, 2004 by KBR of a portion of $300 million of advance payments, without interest; and
-   an extension of time to the original completion dates that average approximately 18 months.
While negotiations are proceeding to reach a final agreement based on the provisions of the April 2004 agreement in principle, there can be no guarantee that an agreement will be achieved.
In the first quarter of 2004, we recorded a charge of $97 million resulting from the April 2004 agreement in principle with Petrobras, as well as adjustments to our estimates of costs expected to be incurred to complete the project. In June 2004, we recorded additional operating losses on our Barracuda-Caratinga project of approximately $310 million. The additional charge resulted from a detailed review of the project indicating higher cost estimates, schedule delays and increased contingencies for the balance of the project until completion. Specifically, in the second quarter, with the integration phase of the Barracuda vessel we experienced a significant reduction in productivity and rework required from the vessel conversion. We have taken steps to mobilize more resources including specialized management personnel in both Houston and South America to oversee the final stages of th e project. We have conducted additional cost and schedule reviews of the remaining project activities, and we have initiated several work process changes in an attempt to expedite work on the project.
As of June 30, 2004:
-   the project was approximately 87% complete;
-   we have recorded an inception-to-date pretax loss of $762 million related to the project, of which $310 million was recorded in the second quarter of 2004; $97 million was recorded in the first quarter of 2004; $238 million was recorded in 2003 ($55 million during the first quarter of 2003, $173 million during the second quarter of 2003 and $10 million in the fourth quarter of 2003); and $117 million was recorded in 2002;
-   the losses recorded include $85 million in liquidated damages; and
-   the probable unapproved claims were reduced from $114 million at December 31, 2003 to zero based upon the April 2004 agreement in principle.
Default provisions. In the event that we were determined to be in default under the contract, and if the project was not completed by us as a result of our default, the project owner may seek direct damages. Those damages could include completion costs in excess of the contract price and interest on borrowed funds, but would exclude consequential damages. The total damages could be up to $500 million plus the return of up to $300 million in advance payments previously received by us to the extent they have not been repaid. A termination of the contract by the project owner could have a material adverse effect on our financial condition and results of operations.
Cash flow considerations. The project owner has procured project finance funding obligations from various lenders to finance the payments due to us under the contract. In addition, the project financing includes borrowing capacity in excess of the original contract amount.
Under the loan documents, the availability date for loan draws expired December 1, 2003 and, therefore, the project owner drew down all remaining available funds on that date. As a condition to the draw-down of the remaining funds, the project owner was required to escrow the funds for the exclusive
 
  8  

 
use of paying project costs. The availability of the escrowed funds can be suspended by the lenders if applicable conditions are not met. With limited exceptions, these funds may not be paid to Petrobras or its subsidiary, which is funding the drilling costs of the project, until all amounts due to us, including amounts due for the change orders as agreed in the April 2004 agreement in principle, are liquidated and paid. While this potentially reduces the risk that the funds would not be available for payment to us, we are not party to the arrangement between the lenders and the project owner and can give no assurance that there will be adequate funding to cover current or future claims and change orders.
We have now begun to fund operating cash shortfalls on the project and are obligated to fund total shortages over the remaining project life. That funding level assumes that, pursuant to amended project agreements implementing the April 2004 agreement in principle, neither we nor the project owner recover additional claims against the other. Estimated cash flows relating to the losses are as follows:

(Millions of dollars)
 
 

 
 
Amount funded through June 30, 2004
 
$
249
 
Amount to be funded during the remainder of 2004,
   
 
 
including repayment of a portion of $300
   
 
 
million advance payments
   
342
 
Amount to be funded during 2005
   
171
 

 
 
Total cash shortfalls
 
$
762
 

 
 

Note 4. Acquisitions and Dispositions
Surface Well Test. In August 2004, we sold our Surface Well Test and Subsea Test Tree product and service lines within our Production Optimization segment to Power Well Service Holdings, LLC, an affiliate of First Reserve Corporation, for approximately $130 million.
Enventure and WellDynamics. In the first quarter of 2004, Halliburton and Shell Technology Ventures (Shell, an unrelated party) agreed to restructure two joint venture companies, Enventure Global Technologies LLC (Enventure) and WellDynamics B.V. (WellDynamics), in an effort to more closely align the ventures with near-term priorities in the core businesses of the venture owners. Prior to this transaction, Enventure (part of our Fluids segment) and WellDynamics (formerly part of our Landmark and Other Energy Services segment) were owned equally by Halliburton and Shell. Shell acquired an additional 33.5% of Enventure, leaving us with 16.5% ownership in return for enhanced and extended agreements and licenses with Shell for its Poroflex™ expandable sand screens and a distribution agreement for its Versaflex™ expandable liner hangers. As a res ult of this transaction, we changed the way we account for our ownership in Enventure from the equity method to the cost method of accounting for investments. Halliburton acquired an additional 1% of WellDynamics from Shell, giving Halliburton 51% ownership and control of day-to-day operations. In addition, Shell received an option to obtain Halliburton’s remaining interest in Enventure for an additional 14% interest in WellDynamics. No gain or loss resulted from the transaction. Beginning in the first quarter of 2004, WellDynamics was consolidated and is now included in our Production Optimization segment. The consolidation of WellDynamics resulted in an increase to our goodwill of $109 million, which was previously carried as equity method goodwill in “Equity in and advances to related companies.”
Halliburton Measurement Systems. In May 2003, we sold certain assets of Halliburton Measurement Systems, which provides flow measurement and sampling systems, to NuFlo Technologies, Inc. for approximately $33 million in cash, subject to post-closing adjustments. The gain on the sale of Halliburton Measurement Systems’ assets was $24 million and is included in our Production Optimization segment.
Wellstream. In March 2003, we sold the assets relating to our Wellstream business, a global provider of flexible pipe products, systems, and solutions, to Candover Partners Ltd. for $136 million in cash. The assets sold included manufacturing plants in Newcastle upon Tyne, United Kingdom, and
 
  9  

 
Panama City, Florida, as well as assets and contracts in Brazil. In addition, Wellstream had $34 million in goodwill recorded at the disposition date. The transaction resulted in a loss of $15 million, which is included in our Landmark and Other Energy Services segment. Included in the loss is the write-off of the cumulative translation adjustment related to Wellstream of approximately $9 million.
Mono Pumps. In January 2003, we sold our Mono Pumps business to National Oilwell, Inc. The sale price of approximately $88 million was paid with $23 million in cash and 3.2 million shares of National Oilwell, Inc. common stock, which were valued at $65 million on January 15, 2003. We recorded a gain of $36 million on the sale in the first quarter of 2003, which was included in our Drilling and Formation Evaluation segment. Included in the gain was the write-off of the cumulative translation adjustment related to Mono Pumps of approximately $5 million. In February 2003, we sold 2.5 million of our 3.2 million shares of the National Oilwell, Inc. common stock for $52 million, which resulted in a gain of $2 million, and in February 2004, we sold the remaining shares for $20 million, resulting in a gain of $6 million. These gains were recorded in “Oth er, net.”

Note 5. Business Segment Information
Our five business segments are organized around how we manage the business: Drilling and Formation Evaluation, Fluids, Production Optimization, Landmark and Other Energy Services, and the Engineering and Construction Group. We sometimes refer to the combination of our Drilling and Formation Evaluation, Fluids, Production Optimization, and Landmark and Other Energy Services segments as the Energy Services Group.
During the first quarter of 2004, the results of WellDynamics were moved from the Landmark and Other Energy Services segment to the Production Optimization segment and prior year segment information has been restated.
The table below presents information on our continuing operations business segments.

 
 
Three Months
Six Months
 
 
Ended June 30
Ended June 30
   

(Millions of dollars)
 
2004
2003
2004
2003

 
 
 
 
 
Revenues:
   
 
   
 
   
 
   
 
 
Drilling and Formation Evaluation
 
$
423
 
$
414
 
$
867
 
$
793
 
Fluids
   
554
   
518
   
1,089
   
998
 
Production Optimization
   
797
   
692
   
1,505
   
1,319
 
Landmark and Other Energy Services
   
130
   
156
   
259
   
281
 

 
 
 
 
 
Total Energy Services Group
   
1,904
   
1,780
   
3,720
   
3,391
 
Engineering and Construction Group
   
3,052
   
1,819
   
6,755
   
3,268
 

 
 
 
 
 
Total
 
$
4,956
 
$
3,599
 
$
10,475
 
$
6,659
 

 
 
 
 
 
 
   
 
   
 
   
 
   
 
 
Operating income (loss):
   
 
   
 
   
 
   
 
 
Drilling and Formation Evaluation
 
$
59
 
$
49
 
$
102
 
$
115
 
Fluids
   
77
   
68
   
137
   
123
 
Production Optimization
   
121
   
112
   
203
   
180
 
Landmark and Other Energy Services
   
14
   
6
   
43
   
(3
)

 
 
 
 
 
Total Energy Services Group
   
271
   
235
   
485
   
415
 
Engineering and Construction Group
   
(277
)
 
(148
)
 
(292
)
 
(167
)
General corporate
   
(20
)
 
(16
)
 
(44
)
 
(35
)

 
 
 
 
 
Total
 
$
(26
)
$
71
 
$
149
 
$
213
 

 
 
 
 
 

Intersegment revenue is immaterial. Our equity in pretax earnings and losses of unconsolidated affiliates that are accounted for on the equity method is included in revenue and operating income of the applicable segment.
Total revenues for the three and six months ended June 30, 2004 included $1.9 billion and $4.5 billion, or 38% and 43% of consolidated revenues, from the United States Government, which were derived almost entirely from our Engineering and Construction Group. Revenue from the United States
 
  10  

 
Government during the three and six months ended June 30, 2003 represented 12% and 10% of consolidated revenues. No other customer represented more than 10% of consolidated revenues in any period presented.

Note 6. Receivables
In April 2004, the expiration date for our Energy Services Group accounts receivable securitization facility was extended to April 2005. We have the ability to sell up to $300 million under the facility. As of June 30, 2004, we had sold $268 million undivided ownership interest to unaffiliated companies.
In May 2004, KBR entered into an agreement to sell, assign, and transfer its entire title and interest in specified accounts receivable to a third party. The face value of the receivables sold to the third party is reflected as a reduction of accounts receivable in our condensed consolidated balance sheets. The amount of receivables which can be sold under the agreement varies based on the amount of eligible KBR receivables at any given time and other factors, and the maximum amount that may be sold and outstanding under this agreement at any given time is $650 million. The total amount of receivables sold under this agreement as of June 30, 2004 was approximately $50 million.

Note 7. Inventories
Inventories are stated at the lower of cost or market. We manufacture in the United States finished products and parts inventories for drill bits, completion products, bulk materials, and other tools that are recorded using the last-in, first-out method totaling $38 million at June 30, 2004 and at December 31, 2003. If the average cost method had been used, total inventories would have been $17 million higher than reported at June 30, 2004 and at December 31, 2003.
Inventories at June 30, 2004 and December 31, 2003 consisted of the following:

 
 
June 30
December 31
(Millions of dollars)
 
2004
2003

 
 
 
Finished products and parts
 
$
522
 
$
503
 
Raw materials and supplies
   
170
   
159
 
Work in process
   
49
   
33
 

 
 
 
Total
 
$
741
 
$
695
 

 
 
 

Finished products and parts are reported net of obsolescence accruals of $123 million at June 30, 2004 and $117 million at December 31, 2003.

Note 8. Restricted Cash
At June 30, 2004, we had restricted cash of $286 million, which primarily consists of:
-   $149 million for the amount of prepetition liabilities that have been paid, as ordered by the bankruptcy court to be set aside subsequent to December 2003, as part of the DII Industries, LLC and Kellogg Brown & Root, Inc. reorganization proceedings. At the time the plan of reorganization becomes final and nonappealable, the cash will become unrestricted. This amount is included in “Other current assets”;
-   $97 million as collateral for potential future insurance claim reimbursements, included in “Other assets”; and
-   $36 million ($24 million in “Other assets” and $12 million in “Other current assets”) primarily related to cash collateral agreements for outstanding letters of credit for various construction projects.
At December 31, 2003, we had restricted cash of $159 million in “Other current assets” and $100 million in “Other assets,” which consisted of similar items as above.
 
  11  

 
Note 9. Property, Plant, and Equipment
In the second quarter of 2004, we implemented a change in accounting estimate to more accurately reflect the useful life of some of the tools of our Drilling and Formation Evaluation segment. This resulted in a $13 million reduction in depreciation expense in the second quarter, thereby reducing our consolidated net loss by $8 million, or $0.02 per share. We extended the useful lives of these tools based on our review of their service lives, technological improvements in the tools, and recent changes to our repair and maintenance practices which helped to extend the lives.

Note 10. Comprehensive Income
The components of other comprehensive income (loss) adjustments to net income (loss) included the following:

 
 
Three Months
Six Months
 
 
Ended June 30
Ended June 30
   

(Millions of dollars)
   
2004
   
2003
   
2004
   
2003
 
Net income (loss)
 
$
(667
)
$
26
 
$
(732
)
$
69
 
Cumulative translation adjustment, net of tax
   
(17
)
 
25
   
3
   
12
 
Realization of losses included in net income (loss)
   
-
   
1
   
-
   
15
 

 
 
 
 
 
Net cumulative translation adjustment, net of tax
   
(17
)
 
26
   
3
   
27
 
Pension liability adjustments
   
-
   
(7
)
 
-
   
(7
)
Unrealized gains (losses) on investments and
   
 
   
 
   
 
   
 
 
derivatives
   
(7
)
 
2
   
(12
)
 
1
 
Total comprehensive income (loss)
 
$
(691
)
$
47
 
$
(741
)
$
90
 

 
 
 
 
 

Accumulated other comprehensive income consisted of the following:

 
 
June 30
December 31
(Millions of dollars)
 
2004
2003
Cumulative translation adjustments
 
$
(60
)
$
(63
)
Pension liability adjustments
   
(245
)
 
(245
)
Unrealized gains (losses) on investments and
   
 
   
 
 
derivatives
   
(2
)
 
10
 
Total accumulated other comprehensive income
 
$
(307
)
$
(298
)

 
 
 

Note 11. Debt
Senior notes due 2007. On January 26, 2004, we issued $500 million aggregate principal amount of senior notes due 2007 bearing interest at a floating rate equal to three-month LIBOR plus 0.75%, payable quarterly. On January 26, 2005, or on any interest payment date thereafter, we have the option to redeem all or a portion of the outstanding notes.
WellDynamics revolving credit line. Upon consolidation of WellDynamics in the first quarter of 2004, our long-term debt included an advance from a revolving credit line with Shell Technology Ventures, which is the minority interest holder of WellDynamics, in the amount of $27 million due April 30, 2005 and bearing interest at a floating rate equal to three-month LIBOR plus 3.25%, payable quarterly. As of June 30, 2004, the $27 million balance was classified as current maturities of long-term debt in our condensed consolidated balance sheet. There was no remaining unused commitment under this WellDynamics revolving credit line. This line of credit contains no working capital or dividend restrictions. Under the terms of the agreement, we may, during the period of 30 days immediately preceding the end of the commitment period, request the lenders to exte nd the availability of the facility for a further period of 364 days from the date of our request.
 
  12  

 
Chapter 11-related financing activities. Our delayed-draw term facility we entered into in the fourth quarter of 2003 expired on June 30, 2004. In the second quarter of 2004, we charged to discontinued operations $11 million in capitalized fees associated with entering into the delayed-draw term facility.
In July 2004, we entered into a $500 million 364-day revolving credit facility for general working capital purposes with terms substantially similar to our $700 million three-year revolving credit facility. The interest rates applicable to these facilities are variable and the borrowings under the revolving credit facilities will be secured by some of our assets until final and nonappealable confirmation of our proposed plan of reorganization is received and our long-term senior unsecured debt is rated BBB or higher (stable outlook) by Standard & Poor’s and Baa2 or higher (stable outlook) by Moody’s Investors Service. As of June 30, 2004, both of these facilities remain undrawn.

Note 12. Asbestos and Silica Obligations and Insurance Recoveries
Summary
Several of our subsidiaries, particularly DII Industries, LLC (DII Industries) and Kellogg Brown & Root, Inc. (Kellogg Brown & Root) have been named as defendants in a large number of asbestos- and silica-related lawsuits. The plaintiffs allege injury primarily as a result of exposure to:
-   asbestos used in products manufactured or sold by former divisions of DII Industries (primarily refractory materials, gaskets, and packing materials used in pumps and other industrial products);
-   asbestos in materials used in our construction and maintenance projects of Kellogg Brown & Root or its subsidiaries; and
-   silica related to sandblasting and drilling fluids operations.
We have substantial insurance to reimburse us for portions of the costs of judgments, settlements, and defense costs for these asbestos and silica personal injury claims. Since 1976, approximately 700,000 asbestos personal injury claims have been filed against us and approximately 240,000 of these claims have been closed through settlements in court proceedings at a total cost of approximately $232 million. Almost all of these claims have been made in separate lawsuits in which we are named as a defendant along with a number of other defendants, often exceeding 100 unaffiliated defendant companies in total. In 2001, we were subject to several large adverse judgments in trial court proceedings. At June 30, 2004, approximately 460,000 asbestos claims were open, and we anticipate resolving all open and future claims in the prepackaged Chapter 11 proceedings of DII Industries, Kellogg Bro wn & Root, and our other affected subsidiaries, which were filed on December 16, 2003. The first and second tables that follow summarize the various charges we have incurred during the three and six months ended June 30, 2004 and 2003. The third table presents a rollforward of our asbestos- and silica-related liabilities and insurance receivables.
 
  13  

 

 
 
Three Months Ended June 30
   
 
 
2004
2003
   

 
 
Continuing
Discontinued
Continuing
Discontinued
(Millions of dollars)
 
Operations
Operations
Operations
Operations

 
 
 
 
 
Asbestos and silica charges:
   
 
   
 
   
 
   
 
 
Insurance receivable write-down
 
$
-
 
$
680
 
$
-
 
$
-
 

 
 
 
 
 
Subtotal
   
-
   
680
   
-
   
-
 

 
 
 
 
 
Asbestos- and silica-related
   
 
   
 
   
 
   
 
 
costs:
   
 
   
 
   
 
   
 
 
Harbison-Walker matters
   
-
   
-
   
-
   
30
 
Professional fees
   
-
   
2
   
-
   
7
 
Cash in lieu of interest
   
-
   
3
   
-
   
5
 
Other costs
   
-
   
11
   
-
   
-
 

 
 
 
 
 
Subtotal
   
-
   
16
   
-
   
42
 

 
 
 
 
 
Pretax asbestos and silica
   
 
   
 
   
 
   
 
 
charges
   
-
   
696
   
-
   
42
 
Tax benefit
   
-
   
(87
)
 
-
   
(26
)

 
 
 
 
 
Total asbestos and silica
   
 
   
 
   
 
   
 
 
charges, net of tax benefit
 
$
-
 
$
609
 
$
   -
 
$
16
 

 
 
 
 
 


 
 
Six Months Ended June 30
   
 
 
2004
2003
   

 
 
Continuing
Discontinued
Continuing
Discontinued
(Millions of dollars)
 
Operations
Operations
Operations
Operations

 
 
 
 
 
Asbestos and silica charges:
   
 
   
 
   
 
   
 
 
59.5 million shares revaluation
 
$
-
 
$
190
 
$
-
 
$
-
 
Insurance receivable write-down
   
-
   
680
   
-
   
-
 

 
 
 
 
 
Subtotal
   
-
   
870
   
-
   
-
 

 
 
 
 
 
Asbestos- and silica-related
   
 
   
 
   
 
   
 
 
costs:
   
 
   
 
   
 
   
 
 
Harbison-Walker matters
   
-
   
-
   
-
   
30
 
Professional fees
   
-
   
8
   
-
   
13
 
Cash in lieu of interest
   
-
   
5
   
-
   
11
 
Other costs
   
-
   
13
   
2
   
-
 

 
 
 
 
 
Subtotal
   
-
   
26
   
2
   
54
 

 
 
 
 
 
Pretax asbestos and silica
   
 
   
 
   
 
   
 
 
charges
   
-
   
896
   
2
   
54
 
Tax benefit
   
-
   
(146
)
 
-
   
(30
)

 
 
 
 
 
Total asbestos and silica
   
 
   
 
   
 
   
 
 
charges, net of tax benefit
 
$
-
 
$
750
 
$
2
 
$
24
 

 
 
 
 
 

 
  14  

 

 
 
 
(Millions of dollars)
 
 

 
 
Asbestos- and silica-related liabilities:
   
 
 
December 31, 2003 balance (of which $2,507 was current)
 
$
4,086
 
59.5 million shares revaluation
   
190
 
Harbison-Walker payment
   
(119
)
Other
   
(4
)

 
 
Asbestos- and silica-related liabilities June 30, 2004
   
 
 
balance (of which $2,399 was current)
 
$
4,153
 

 
 
Insurance for asbestos- and silica-related liabilities:
   
 
 
December 31, 2003 balance
 
$
(2,134
)
Insurance settlement write-down
   
680
 
Other
   
5
 

 
 
Insurance for asbestos- and silica-related liabilities
   
 
 
June 30, 2004 balance (of which $981 was current)
 
$
(1,449
)

 
 

Prepackaged Chapter 11 proceedings and recent insurance developments
Prepackaged Chapter 11 proceedings. DII Industries, Kellogg Brown & Root, and six other subsidiaries filed Chapter 11 proceedings on December 16, 2003 in bankruptcy court in Pittsburgh, Pennsylvania. With the filing of the Chapter 11 proceedings, all asbestos and silica personal injury claims and related lawsuits against Halliburton and our affected subsidiaries were stayed. See Note 13 for more information.
Our subsidiaries sought Chapter 11 protection because Sections 524(g) and 105 of the Bankruptcy Code may be used to discharge current and future asbestos and silica personal injury claims against us and our subsidiaries. Upon final and nonappealable confirmation of the plan of reorganization, current and future asbestos and silica personal injury claims against us and our affiliates will be channeled into trusts established for the benefit of claimants under Sections 524(g) and 105 of the Bankruptcy Code, thus releasing Halliburton and its affiliates from those claims. The plan of reorganization will become effective after the affirmation by the United States District Court of the confirmation order of the bankruptcy court becomes final and nonappealable. The affirmation will be final and nonappealable 30 days after entry of the order of affirmation (such order was entered on July 26, 2004) if no appeals are filed or, if appeals are filed, once the appeals are withdrawn by those appealing or disposed of by an appeals court.
A prepackaged Chapter 11 proceeding is one in which a debtor seeks approval of a plan of reorganization from affected creditors before filing for Chapter 11 protection. Prior to proceeding with the Chapter 11 filing, our affected subsidiaries solicited acceptances to a proposed plan of reorganization from known present asbestos and silica claimants. In the fourth quarter of 2003, valid votes were received from approximately 364,000 asbestos claimants and approximately 21,000 silica claimants, representing substantially all known claimants. Of the votes validly cast, over 98% of voting asbestos claimants and over 99% of voting silica claimants voted to accept the proposed plan of reorganization, meeting the voting requirements of Chapter 11 of the Bankruptcy Code for approval of the proposed plan. The preapproved proposed plan of reorganization was filed as part of the Chapter 11 proce edings.
On July 21, 2004, the bankruptcy court entered an order, effective as of July 16, 2004, confirming the proposed plan of reorganization to implement our proposed asbestos and silica settlement. On July 26, 2004, certain of our insurance companies filed a notice of appeal concerning the bankruptcy court’s confirmation. Also on July 26, 2004, the United States District Court for the Western District of Pennsylvania affirmed the confirmation order. On August 3, 2004, certain of our insurance companies filed a motion to vacate the District Court's affirmatin order in order to protect their appeal rights. If our previously announced agreements in principle with our insurance companies are finalized and approved by the relevant bankruptcy courts, we believe that the insurance companies will dismiss their notice of appeal, that the District Court’s affirmation order will become final and nonappealable, and that the plan of reorganization will become effective.
The proposed plan of reorganization, which is consistent with the definitive settlement agreements reached with our asbestos and silica personal injury claimants in early 2003, provides that, if and when an
 
  15  

 
order confirming the proposed plan of reorganization becomes final and nonappealable, the following will be contributed to trusts for the benefit of current and future asbestos and silica personal injury claimants:
-   up to approximately $2.3 billion in cash;
-   59.5 million shares of Halliburton common stock;
-   a one-year non-interest-bearing note of $31 million for the benefit of asbestos claimants;
-   a silica note with an initial payment into a silica trust of $15 million. Subsequently, the note provides that we will contribute an amount to the silica trust balance at the end of each year for the next 30 years to bring the silica trust balance to $15 million, $10 million, or $5 million based upon a formula which uses average yearly disbursements from the trust to determine that amount. The note also provides for an extension of the note for 20 additional years under certain circumstances. We have estimated the amount of this note to be approximately $21 million. We will periodically reassess our valuation of this note based upon our projections of the amounts we believe we will be required to fund into the silica trust; and
-   insurance proceeds, if any, between $2.3 billion and $3.0 billion received by DII Industries and Kellogg Brown & Root. However, if the proposed settlements with our insurance companies are completed on the terms announced or proposed, insurance recoveries will not exceed $2.3 billion.
We intend to fund the trusts 30 days after the affirmation by the United States District Court becomes final and nonappealable, but no earlier than October 29, 2004, which is the earliest date the cash amount to be funded will be finalized.
In connection with reaching an agreement with representatives of asbestos and silica claimants to limit the cash required to settle pending claims to $2.775 billion, DII Industries paid $311 million to the claimants in December 2003. We also agreed to guarantee the payment of certain claims, and, in accordance with settlement agreements, we made additional payments of $119 million, plus an additional $4 million in lieu of interest, in June 2004. We expect to pay an additional approximately $50 million in pending claims under these settlement agreements 30 days after the proposed plan of reorganization becomes final and nonappealable. We may not be entitled to reimbursement for these payments if the proposed plan of reorganization does not become effective in accordance with its terms.
Our proposed plan of reorganization calls for a portion of our total asbestos and silica liability to be settled by contributing 59.5 million shares of Halliburton common stock into the trusts. We will adjust our asbestos and silica liability related to the shares if the average value of Halliburton common stock for the five days immediately prior to and including the end of each fiscal quarter has increased by 5% or more from the most recent valuation of the shares. At June 30, 2004, the liability was valued at $1.7 billion, an increase of $190 million from December 31, 2003, all of which was recorded during the first quarter of 2004. The value of the shares to be contributed was classified as a long-term liability on our consolidated balance sheets, and the shares were not included in our calculation of basic or diluted earnings per share. If the shares had been included in the calc ulation as of the beginning of 2004, our diluted earnings per share from continuing operations for the six months ended June 30, 2004 would have been reduced by $0.01 and for the three months ended June 30, 2004 would have been antidilutive. When and if we receive final and nonappealable confirmation of our proposed plan of reorganization, we will:
-   increase or decrease our asbestos and silica liability to value the 59.5 million shares of Halliburton common stock based on the value of Halliburton stock on the date of final and nonappealable confirmation of our proposed plan of reorganization;
-   reclassify from a long-term liability to shareholders’ equity the final value of the 59.5 million shares of Halliburton common stock; and
-   include the 59.5 million shares in our calculations of earnings per share on a prospective basis.
We understand that the United States Congress may consider adopting legislation that would establish a national trust fund as the exclusive means for recovery for asbestos-related disease. We are uncertain as to what contributions we would be required to make to a national trust, if any, although it is
 
  16  

 
possible that they could be substantial and that they could continue for several years. Our level of participation in and contribution to a national trust could be greater or less than it otherwise would have been as a result of having subsidiaries that have filed Chapter 11 proceedings due to asbestos liability.
Recent insurance developments. In January 2004, we reached a comprehensive agreement with Equitas to settle our insurance claims against certain underwriters at Lloyd's of London, reinsured by Equitas. The settlement, if all conditions precedent are satisfied, will resolve all asbestos-related claims made against Lloyd's underwriters by us and by each of our subsidiary and affiliated companies, including DII Industries, Kellogg Brown & Root, and their subsidiaries that have filed Chapter 11 proceedings as part of our proposed settlement. Provided that there is final and nonappealable confirmation of the plan of reorganization in the Chapter 11 proceedings and the current United States Congress does not pass national asbestos litigation reform legislation before January 5, 2005, Equitas will pay us $575 million, representing approximately 60% of the appli cable limits of liability that we believe DII Industries had substantial likelihood of recovering from Equitas. The first payment of $500 million, which is classified as a current receivable as of June 30, 2004, will occur within 15 working days of the later of January 5, 2005 or the date on which the order of the bankruptcy court confirming DII Industries' plan of reorganization becomes final and nonappealable. A second payment of $75 million will be made 18 months after the first payment.
In May 2004, we entered into nonbinding agreements in principle with representatives of the London Market insurance companies that, if implemented, would settle insurance disputes with substantially all the solvent London Market insurance companies for asbestos- and silica-related claims and all other claims under the applicable insurance policies. The agreements in principle with the London Market insurance companies are subject to board of directors’ approval of all parties, agreement by all remaining London Market insurance companies, and an order by the bankruptcy court confirming our proposed plan of reorganization that has become final and nonappealable. Currently, we expect to receive cash payments during the years of 2005 through 2009.
We also expect to shortly enter into a nonbinding agreement in principle with our solvent domestic insurance companies that, if implemented, would settle asbestos- and silica-related claims and all other claims under the applicable insurance policies and terminate all the applicable insurance policies. The final settlement agreement with the domestic insurance companies would be subject to board of directors’ approval of all parties, an order by the bankruptcy court approving the final settlement agreement, agreement by Federal-Mogul Products, Inc. (Federal-Mogul) and Cooper Industries, Inc. (Cooper) concerning DII Industries’ rights to access certain of the insurance policies, approval by the Federal-Mogul bankruptcy court of the agreement with Federal-Mogul and Cooper, and an order by the bankruptcy court confirming our proposed plan of reorganization that has become final and nonappealable.
These proposed settlements with our insurance companies are subject to numerous conditions. Although we are working toward implementation of these proposed settlements, there can be no assurance that the transactions contemplated by these agreements in principle can be completed on the terms announced.
Under the terms of our announced insurance settlements and proposed insurance settlements, we expect to receive cash proceeds with a nominal amount of $1.5 billion and a present value of approximately $1.4 billion for our asbestos- and silica-related insurance receivables. The present value was determined by discounting the expected future cash payments with a discount rate implicit in the settlements which is approximately 5.5% related to the domestic insurance companies. This discount will be accreted as interest income (classified as discontinued operations) over the life of the expected future cash payments beginning in the third quarter of 2004.
Our December 31, 2003 estimate of our asbestos- and silica-related insurance receivables already included the charge for the settlement amount under the Equitas agreement reached in January 2004, as well as certain other probable settlements with companies for which we could reasonably estimate the amount of the settlement. In the second quarter of 2004, we reduced the amount recorded as insurance
 
  17  

 
receivables for asbestos- and silica-related liabilities insured by domestic companies based upon the proposed agreement in principle, resulting in a pretax charge to discontinued operations of approximately $680 million.
Other insurance matters
Harbison-Walker Chapter 11 proceedings. A large portion of our asbestos claims relate to alleged injuries from asbestos used in a small number of products manufactured or sold by Harbison-Walker Refractories Company, whose operations DII Industries acquired in 1967 and spun off in 1992. At the time of the spin-off, Harbison-Walker assumed liability for asbestos claims filed after the spin-off, and it agreed to defend and indemnify DII Industries from liability for those claims, although DII Industries continues to have direct liability to tort claimants for all post-spin-off refractory asbestos claims. DII Industries retained responsibility for all asbestos claims pending as of the date of the spin-off. The agreement governing the spin-off provided that Harbison-Walker would have the right to access DII Industries’ historic insurance coverage for the as bestos-related liabilities that Harbison-Walker assumed in the spin-off.
In July 2001, DII Industries determined that the demands that Harbison-Walker was making on the shared insurance policies were not acceptable to DII Industries and that Harbison-Walker probably would not be able to fulfill its indemnification obligations to DII Industries. Accordingly, DII Industries took up the defense of unsettled post-spin-off refractory claims that name it as a defendant in order to prevent Harbison-Walker from unnecessarily eroding the insurance coverage both companies access for these claims.
On February 14, 2002, Harbison-Walker filed a voluntary petition for reorganization under Chapter 11 of the Bankruptcy Code. In its initial Chapter 11 filings, Harbison-Walker stated it would seek to utilize Sections 524(g) and 105 of the Bankruptcy Code to propose and seek confirmation of a plan of reorganization that would provide for distributions for all legitimate pending and future asbestos and silica claims asserted directly against Harbison-Walker or asserted against DII Industries. In order to protect the shared insurance from dissipation, DII Industries began to assist Harbison-Walker in its Chapter 11 proceedings as follows:
-   on February 14, 2002, DII Industries paid $40 million to Harbison-Walker’s United States parent holding company, RHI Refractories Holding Company (RHI Refractories);
-   DII Industries agreed to provide up to $35 million in debtor-in-possession financing to Harbison-Walker ($5 million was paid in 2002 and the remaining $30 million was paid in 2003); and
-   during 2003, DII Industries purchased $50 million of Harbison-Walker’s outstanding insurance receivables, of which $10 million were estimated to be uncollectible.
In 2003, DII Industries entered into a definitive agreement with Harbison-Walker. This agreement is subject to court approval in Harbison-Walker's Chapter 11 proceedings and would channel all asbestos and silica personal injury claims against Harbison-Walker and certain of its affiliates to the trusts created in DII Industries’ and Kellogg Brown & Root’s Chapter 11 proceedings. Our asbestos and silica obligations and related insurance recoveries recorded as of June 30, 2004 and December 31, 2003 reflect the terms of this definitive agreement.
In the first quarter of 2004, we entered into an agreement with RHI Refractories to settle remaining funding issues relating to Harbison-Walker. The agreement calls for a $10 million payment to RHI Refractories and a $1 million payment to our asbestos and silica trusts on behalf of RHI Refractories. These amounts were expensed during 2003. These payments will be made shortly after the effective date of our plan of reorganization.
London-based insurance companies. Equitas and other London-based companies have attempted to impose more restrictive documentation requirements on DII Industries and its affiliates than are currently required under existing coverage-in-place agreements related to certain asbestos claims. Coverage-in-place agreements are settlement agreements between policyholders and the insurance companies specifying the terms and conditions under which coverage will be applied as claims are presented for payment. These agreements in an asbestos claims context govern such things as what events will be deemed to trigger
 
  18  

 
coverage, how liability for a claim will be allocated among insurance companies, and what procedures the policyholder must follow in order to obligate the insurer to pay claims. These insurance companies stated that the new restrictive requirements are part of an effort to limit payment of settlements to claimants who are truly impaired by exposure to asbestos and can identify the product or premises that caused their exposure.
DII Industries is a plaintiff in two lawsuits against a number of London-based insurance companies asserting DII Industries’ rights under an existing coverage-in-place agreement and under insurance policies not yet subject to coverage-in-place agreements. DII Industries believes that the more restrictive documentation requirements are inconsistent with the current coverage-in-place agreements and are unenforceable. The insurance companies that DII Industries has sued continue to pay larger claim settlements where the more restrictive documentation is obtained or where court judgments are entered. Likewise, they continue to pay previously agreed amounts of defense costs that DII Industries incurs defending claims.
In light of the Bankruptcy Court’s approval of our settlement agreement with Equitas, we have dismissed Equitas from the cases that we filed against them. If, however, the conditions precedent to payment are not satisfied, we have the right to re-file these cases against Equitas.
Federal-Mogul. A significant portion of the insurance coverage applicable to Worthington Pump, a former division of DII Industries, is alleged by Federal-Mogul, and Cooper to be shared with them. In 2001, Federal-Mogul and a large number of its affiliated companies filed a voluntary petition for reorganization under Chapter 11 of the Bankruptcy Code in the bankruptcy court in Wilmington, Delaware. In response to Federal-Mogul’s allegations, DII Industries filed a lawsuit on December 7, 2001 in Federal-Mogul’s Chapter 11 proceedings asserting DII Industries’ rights to asbestos insurance coverage under historic general liability policies issued to Studebaker-Worthington, Inc. and its successor. The parties to this litigation have agreed to mediate this dispute. A number of insurance companies who have agreed to coverage-in-place agreements with DII Industries have suspended payment under the shared Worthington Pump policies until the Federal-Mogul bankruptcy court resolves the insurance issues. Consequently, the effect of the Federal-Mogul Chapter 11 proceedings on DII Industries’ rights to access this shared insurance is uncertain. During the first quarter of 2004, we reached an agreement with Federal-Mogul which resolved all disputes regarding the insurance coverage provided by Equitas.
In regard to the Federal-Mogul Chapter 11 proceedings, we are currently in negotiations with Federal-Mogul, our insurance companies, and Cooper to obtain their consent and support of a partitioning of the insurance policies shared by us, Federal-Mogul and Cooper. Under the terms of the proposed settlement, DII Industries would be allocated 50% of the limits of any applicable insurance policy, and the remaining 50% of limits of the insurance policies would be allocated to the remaining policyholders, such as Federal-Mogul and Cooper. The negotiations concerning this proposed settlement, the consummation of which is necessary to effectuate the settlements with the London Market insurance companies and the domestic insurance companies, are continuing.
Excess insurance on construction claims. Kellogg Brown & Root does not have primary insurance coverage related to construction claims. However, excess insurance coverage policies with other insurance companies were in place. On March 20, 2002, Kellogg Brown & Root filed a lawsuit against the insurance companies that issued these excess insurance policies, seeking to establish the specific terms under which it can obtain reimbursement for costs incurred in settling and defending construction claims. Until this lawsuit is resolved, the scope of the excess insurance coverage will remain uncertain, and as such, we have not recorded any recoveries related to excess insurance coverage.

Note 13. Chapter 11 Reorganization Proceedings
On December 16, 2003, the following wholly owned subsidiaries of Halliburton (collectively, the Debtors or Debtors-in-Possession) filed Chapter 11 proceedings in bankruptcy court in Pittsburgh, Pennsylvania:
-   DII Industries, LLC;
-   Kellogg Brown & Root, Inc.;
 
  19  

 
-   Mid-Valley, Inc.;
-   KBR Technical Services, Inc.;
-   Kellogg Brown & Root Engineering Corporation;
-   Kellogg Brown & Root International, Inc. (a Delaware corporation);
-   Kellogg Brown & Root International, Inc. (a Panamanian corporation); and
-   BPM Minerals, LLC.
On May 10, 2004, the bankruptcy court completed hearings on confirmation of the proposed plan of reorganization. On July 21, 2004, the bankruptcy court entered an order, effective as of July 16, 2004, confirming the proposed plan of reorganization to implement our proposed asbestos and silica settlement. On July 26, 2004, certain of our insurance companies filed a notice of appeal concerning the bankruptcy court’s confirmation. Also on July 26, 2004, the United States District Court for the Western District of Pennsylvania affirmed the confirmation order. If our previously announced agreements in principle with our insurance companies are finalized and approved by the relevant bankruptcy courts, we believe that the insurance companies will dismiss their notice of appeal, that the District Court’s affirmation order will become final and nonappealable, and that the plan of reo rganization will become effective.
The affected subsidiaries will continue to be wholly owned by Halliburton Company under the proposed plan. Halliburton Company (the registrant), Halliburton's Energy Services Group, and Kellogg Brown & Root's government services businesses are not included in the Chapter 11 filing. Upon effectiveness of the plan of reorganization, current and future asbestos and silica personal injury claims filed against us and our subsidiaries will be channeled into trusts established under Sections 524(g) and 105 of the Bankruptcy Code for the benefit of claimants, thus releasing Halliburton and its affiliates from those claims.
Debtors-in-Possession financial statements. Under the Bankruptcy Code, we are required to periodically file with the bankruptcy court various documents, including financial statements of the Debtors-in-Possession. These financial statements are prepared according to requirements of the Bankruptcy Code. While these financial statements accurately provide information required by the Bankruptcy Code, they are unconsolidated, unaudited, and prepared in a format different from that used in our condensed consolidated financial statements filed under the securities laws and from that used in the condensed combined financial statements that follow. For example, the “Right to Halliburton shares” are currently adjusted to fair value periodically in the financial statements prepared for the bankruptcy court, but not in the condensed combined financial statements. Accordingly, we believe the substance and format of the financial statements prepared for the bankruptcy court do not allow meaningful comparison with the following condensed combined financial statements.
Basis of presentation. We continue to consolidate the Debtors in our consolidated financial statements. While generally it is appropriate to deconsolidate a subsidiary during its Chapter 11 proceedings on the basis that control no longer rests with the parent, the facts and circumstances particular to our situation support the continued consolidation of these subsidiaries. Specifically:
-   substantially all affected creditors have approved the terms of the plan of reorganization and related transactions;
-   the entire duration of the Chapter 11 proceedings is likely to be short, anticipated to be less than one year, excluding any potential appeals;
-   the Debtors were solvent and filed Chapter 11 proceedings to resolve asbestos and silica claims rather than as a result of insolvency; and
-   the plan of reorganization provides that we will continue to own 100% of the equity of the Debtors upon completion of the plan of reorganization. The plan of reorganization will not impact our equity ownership of the Debtors.
All reorganization items, including but not limited to all professional fees and provisions for losses, are included as discontinued operations in both our condensed consolidated financial statements and the condensed combined financial statements of the Debtors-in-Possession. During the first half of 2004,
 
  20  

 
we recorded a total of $21 million as reorganization items, which consisted primarily of professional fees and $11 million of bridge loan fees, and disbursed $8 million in cash for reorganization items.
Furthermore, certain claims against the Debtors existing before the Chapter 11 filing are considered liabilities subject to compromise. The principal categories of claims subject to compromise included the following:
-   $2.4 billion at June 30, 2004 and $2.5 billion at December 31, 2003 of current asbestos- and silica-related liabilities; and
-   $1.8 billion at June 30, 2004 and $1.6 billion at December 31, 2003 of noncurrent asbestos- and silica-related liabilities.
Prior to the filing of the Chapter 11 proceedings, DII Industries was the parent for all Energy Services Group and KBR operations. As part of a prefiling corporate restructuring, immediately prior to the Chapter 11 filing, DII Industries distributed the Energy Services Group operations to Halliburton Company, while the operations of KBR continued to be conducted through subsidiaries of DII Industries. The condensed combined balance sheet as of December 31, 2003 of the Debtors-in-Possession was prepared as if this distribution had taken place as of January 1, 2003.

Debtors-in-Possession
Condensed Combined Statements of Operations
(Unaudited)
(Millions of dollars)

 
 
Three Months Ended
Six Months Ended
 
 
June 30, 2004
June 30, 2004

 
 
 
Revenues
 
$
473
 
$
930
 
Equity in earnings (losses) of majority-owned
   
 
   
 
 
subsidiaries
   
(1
)
 
(25
)

 
 
 
Total revenues
   
472
   
905
 
Operating costs and expenses
   
679
   
1,178
 

 
 
 
Operating loss
   
(207
)
 
(273
)
Nonoperating income
   
11
   
26
 

 
 
 
Loss from continuing operations before income
   
 
   
 
 
taxes
   
(196
)
 
(247
)
Income tax benefit
   
76
   
82
 
Loss from continuing operations
   
(120
)
 
(165
)
Loss from discontinued operations, net of tax
   
 
   
 
 
benefit of $87 and $146
   
(609
)
 
(750
)
Net loss
 
$
(729   
)
$
(915   
)

 
 
 

The subsidiaries of DII Industries that are not included in the Chapter 11 filing are presented in the condensed combined financial statements using the equity method of accounting. These subsidiaries had revenue of $2.6 billion and operating loss of $52 million for the three months ended June 30, 2004 and revenue of $5.8 billion and operating loss of $44 million for the six months ended June 30, 2004. These subsidiaries had assets of $2.3 billion and liabilities of $2.4 billion as of June 30, 2004, and assets of $2.3 billion and liabilities of $2.3 billion as of December 31, 2003.
 
  21  

 
Debtors-in-Possession
Condensed Combined Balance Sheets
(Unaudited)
(Millions of dollars)

 
 
June 30
December 31
 
 
2004
2003

 
 
 
Assets
   
 
   
 
 
Current assets:
   
 
   
 
 
Cash and equivalents
 
$
152
 
$
108
 
Receivables:
   
 
   
 
 
Trade, net
   
146
   
191
 
Unbilled insurance for asbestos- and silica-related liabilities
   
889
   
-
 
Intercompany, net
   
-
   
50
 
Unbilled work on uncompleted contracts
   
141
   
60
 
Other, net
   
89
   
75
 

 
 
 
Total receivables, net
   
1,265
   
376
 
Inventories
   
23
   
23
 
Right to Halliburton shares (1)
   
1,547
   
1,547
 
Restricted cash – prepetition liability payments
   
149
   
37
 
Other current assets
   
177
   
43
 

 
 
 
Total current assets
   
3,313
   
2,134
 
Property, plant, and equipment, net
   
92
   
91
 
Goodwill, net
   
188
   
188
 
Investments in majority-owned subsidiaries
   
1,530
   
1,567
 
Insurance for asbestos-and silica-related liabilities
   
468
   
2,038
 
Noncurrent deferred income taxes
   
558
   
436
 
Other assets
   
106
   
257
 

 
 
 
Total assets
 
$
6,255
 
$
6,711
 

 
 
 
Liabilities and Shareholders’ Equity
   
 
   
 
 
Current liabilities:
   
 
   
 
 
Accounts payable:
   
 
   
 
 
Trade
 
$
127
 
$
13
 
Intercompany, net
   
254
   
-
 
Accrued employee compensation and benefits
   
18
   
30
 
Advance billings on uncompleted contracts
   
77
   
23
 
Prepetition liabilities not subject to compromise
   
520
   
834
 
Current prepetition asbestos- and silica-related liabilities
   
 
   
 
 
subject to compromise
   
2,399
   
2,507
 
Other current liabilities
   
-
   
14
 

 
 
 
Total current liabilities
   
3,395
   
3,421
 
Prepetition liabilities not subject to compromise
   
126
   
137
 
Noncurrent prepetition asbestos- and silica-related liabilities
   
 
   
 
 
subject to compromise
   
1,754
   
1,579
 
Other liabilities
   
20
   
2
 

 
 
 
Total liabilities
   
5,295
   
5,139
 

 
 
 
Shareholders’ equity
   
960
   
1,572
 

 
 
 
Total liabilities and shareholders’ equity
 
$
6,255
 
$
6,711
 

 
 
 

(1)   Represents an option for DII Industries to acquire 59.5 million shares of Halliburton stock at no cost and was valued at $26.00.
 
  22  

 
Debtors-in-Possession
Condensed Combined Statement of Cash Flows
(Unaudited)
(Millions of dollars)

 
 
Six Months Ended
 
 
June 30, 2004
Total cash flows from operating activities
 
$
(165
)

 
 
Total cash flows from investing activities
   
(6
)

 
 
Total cash flows from activities with Halliburton
   
212
 

 
 
Effect of exchange rate changes on cash
   
3
 
Increase in cash and equivalents
   
44
 
Cash and equivalents at beginning of period
   
108
 

 
 
Cash and equivalents at end of period
 
$
152
 

 
 

There can be no assurance that we will obtain all of the required judicial approval of the proposed plan of reorganization or any revised plan of reorganization acceptable to us. A prolonged Chapter 11 proceeding could adversely affect the Debtors’ relationships with customers, suppliers, and employees, which in turn could adversely affect the Debtors’ competitive position, financial condition, and results of operations. In addition, if the Debtors are unsuccessful in obtaining final and nonappealable confirmation of a plan of reorganization, the assets of the Debtors could be liquidated in the Chapter 11 proceedings, which could have a material adverse effect on Halliburton.

Note 14. Other Commitments and Contingencies
United States government contract work. We provide substantial work under our government contracts business to the United States Department of Defense and other governmental agencies, including worldwide United States Army logistics contracts, known as LogCAP, and contracts to rebuild Iraqs petroleum industry, known as RIO I and PCO Oil South (formerly RIO II). Our government services revenue related to Iraq totaled approximately $1.7 billion and $4 billion for the three and six months ended June 30, 2004. Our units operating in Iraq and elsewhere under government contracts such as LogCAP, RIO I, and PCO Oil South consistently review the amounts charged and the services performed under these cont racts. Our operations under these contracts are also regularly reviewed and audited by the Defense Contract Audit Agency (DCAA) and other governmental agencies. When issues are found during the governmental agency audit process, these issues are typically discussed and reviewed with us in order to reach a resolution.
The results of a preliminary audit by the DCAA in December 2003 alleged that we may have overcharged the Department of Defense by $61 million in importing fuel into Iraq. After a review, the Army Corps of Engineers, which is our client and oversees the project, concluded that we obtained a fair price for the fuel. However, Department of Defense officials thereafter referred the matter to the agencys inspector general, which we understand has commenced an investigation.
We have had inquiries in the past by the DCAA and the civil fraud division of the United States Department of Justice into possible overcharges for work performed during 1996 through 2000 under a contract in the Balkans, which inquiry has not yet been completed by the Department of Justice. Based on an internal investigation, we credited our customer approximately $2 million during 2000 and 2001 related to our work in the Balkans as a result of billings for which support was not readily available. We believe that the preliminary Department of Justice inquiry relates to potential overcharges in connection with a part of the Balkans contract under which approximately $100 million in work was done. The Department of Justice has not alleged any overcharges, and we believe that any allegation of overcharges would be without merit.
 
  23  

 
On January 22, 2004, we announced the identification by our internal audit function of a potential overbilling of approximately $6 million by one of our subcontractors under the LogCAP contract in Iraq for services performed during 2003. In accordance with our policy and government regulation, the potential overcharge was reported to the Department of Defense Inspector Generals office as well as to our customer, the Army Materiel Command. On January 23, 2004, we issued a check in the amount of $6 million to the Army Materiel Command to cover that potential overbilling while we conducted our own investigation into the matter. Later in the first quarter of 2004, we determined that the amount of overbilling w as $4 million and the subcontractor billing should have been $2 million for the services provided. As a result, we have processed payment for $2 million and have billed our customer that amount. We are continuing to investigate whether third-party subcontractors paid, or attempted to pay, one or two of our former employees in connection with the billing.
We understand that the United States Department of Justice and an Assistant United States Attorney based in Illinois are investigating some of these matters. We also understand that former employees of KBR have received subpoenas and have given or may give grand jury testimony relating to some of these matters. If criminal wrongdoing were found, criminal penalties could range up to the greater of $500,000 in fines per count for a corporation, or twice the gross pecuniary gain or loss.
During 2003, the DCAA raised issues relating to our invoicing to the Army Materiel Command for food services for soldiers and supporting civilian personnel in Iraq and Kuwait. We believe the issues raised by the DCAA relate to the difference between the number of troops the Army Materiel Command directed KBR to support and the number of soldiers actually served at dining facilities for United States troops and supporting civilian personnel in Iraq and Kuwait. In the first quarter of 2004, we reviewed our DFACs in our Iraq and Kuwait areas of operation and have billed and continue to bill for all current DFAC costs. During the second quarter of 2004, we received notice from the DCAA that it is recommending withholding a portion of all our DFAC billings. The amount withheld totaled approximately $203 million as of June 30, 2004. The DCAA is continuing to recommend withholding 19.35% of payments on future DFAC billings relating to subcontracts entered into prior to February 2004. We are negotiating with our customer, the Army Materiel Command, and the DCAA in an attempt to settle these issues.
During 2004, the Army Materiel Command issued mandates that could cause it to withhold 15% from our invoices to be paid after August 15, 2004 until our task orders under the LogCAP contract are definitized. We do not believe the potential 15% withholding will have a significant or sustained impact on our liquidity because the withholding is temporary and ends once the definitization process is complete.
During the second quarter of 2004, the Army Corps of Engineers withheld $57 million of our invoices related to a portion of our RIO I contract pending completion of the definitization process. All ten definitization proposals required under this contract have been submitted and two have been finalized. The remaining eight are under review by the DCAA. These withholdings represent the amount invoiced in excess of 85% of the currently estimated amounts. The Army Corps of Engineers also could withhold similar amounts from future invoices under our RIO I contract until our task orders under the RIO I contract are definitized. We do not believe the withholding will have a significant or sustained impact on our liquidity because the withholding is temporary and ends once the definitization process is complete.
Securities and Exchange Commission (SEC) investigation. In August 2004, we reached a settlement in the investigation by the SEC involving our 1998 and 1999 disclosure of and accounting for the recognition of revenue from unapproved claims on long-term construction projects. Our settlement with the SEC covers a failure to disclose a 1998 change in accounting practice. We disclosed the change in accounting practice in our 1999 Form 10-K and continued to do so in subsequent periods. The SEC did not determine that we departed from generally accepted accounting principles, nor did it find errors in accounting or fraud. We neither admitted nor denied the SEC’s findings, but agreed to pay a $7.5 million civil penalty, and have taken a charge of that amount in the second quarter of 2004. As part of the settlement, the company agreed to cease and desist f rom committing or causing future securities law violations.
 
  24  

 
Securities and related litigation. On June 3, 2002, a class action lawsuit was filed against us in federal court on behalf of purchasers of our common stock alleging violations of the federal securities laws. After that date, approximately twenty similar class actions were filed against us. Several of those lawsuits also named as defendants Arthur Andersen, LLP, our independent accountants for the period covered by the lawsuits, and several of our present or former officers and directors. Those lawsuits allege that we violated federal securities laws during the period from approximately May 1998 until approximately May 22, 2002, in failing to disclose a change in the manner in which we accounted for revenue associated with unapproved claims on long-term engineering and construction contracts, and that we overstated revenue by accruing the unapproved c laims in amounts allegedly in excess of those that were probable of recovery and could be reliably estimated (the “contract claims”). On October 11, 2002, a shareholder derivative action arising out of the same facts and circumstances was filed in the District Court of Harris County, Texas against a number of our present and former officers and directors. That action was subsequently dismissed upon our motion. On March 12, 2003, another shareholder derivative action arising out of the same events and circumstances was filed in federal court against some of our present and former officers and directors. The class action cases were later consolidated and the amended consolidated class action complaint, styled Richard Moore v. Halliburton, was filed and served upon us on or about April 11, 2003. In early May 2003, we announced that we had entered into a written memorandum of understanding setting forth the terms upon which both the consolidated cases and the federal court derivative action would be settled, and in June 2003, the lead plaintiffs’ lawyer in the Moore action filed a motion for leave to file a second amended consolidated complaint. The court granted that motion on or about January 28, 2004. In addition to restating the contract claims, the second amended consolidated complaint includes nondisclosure claims arising out of the 1998 acquisition of Dresser Industries, Inc. by Halliburton (the “Dresser claims”) that were included in the settlement discussions leading up to the signing of the memorandum of understanding and are among the claims to be resolved by the terms of the proposed settlement of the consolidated class actions.
The memorandum of understanding called for Halliburton to pay $6 million, which is to be funded by insurance proceeds. After the May 2003 announcement regarding the memorandum of understanding, one of the lead plaintiffs in the consolidated class actions announced that it was dissatisfied with the lead plaintiffs’ counsel’s handling of settlement negotiations and what the dissident plaintiff regarded as inadequate communications by the lead plaintiffs’ counsel. The dissident lead plaintiff further asserted that it believes the lead plaintiffs’ counsel failed in connection with the settlement negotiations to take into account the alleged value of certain Dresser claims and that the $6 million proposed settlement figure is therefore inadequate. It is unclear whether this dispute within the ranks of the lead plaintiffs will have any impact upon the process of approval of the settlement and whether the dissident plaintiff will object to the settlement at the time of the fairness hearing or opt out of the class action for settlement purposes. The process by which the parties will seek approval of the settlement is ongoing. The attorneys representing the dissident plaintiff filed yet another class action case in August 2003, raising allegations similar to those raised in the second amended consolidated complaint regarding the contract and Dresser claims. We believe that the allegations in that action, styled Kimble v. Halliburton Company, et al., are without merit and we intend to vigorously defend against them. We also believe that those new allegations fall within the scope of the memorandum of understanding and that the settlement, if approved and consummated, will dispose of those claims in their entirety with respect to all members of the class who do not validly and timely elect not to participate in the settlement. That action was recently consolidated within the Richard Moore v. Halliburton case. On June 7, 2004, the court entered an order preliminarily approving the settlement and scheduling the final hearing to determine fairness of the proposed settlement for August 26, 2004 and directing that notice be sent to class members.
As of the date of this filing, the $6 million settlement amount for the consolidated actions and the federal court derivative action was fully covered by our directors’ and officers’ insurance carrier. We have accrued a contingent liability for the $6 million settlement and a $6 million insurance receivable from the insurance carrier.
 
  25  

 
BJ Services Company patent litigation. On April 12, 2002, a federal court jury in Houston, Texas, returned a verdict against Halliburton Energy Services, Inc., a wholly owned subsidiary, in a patent infringement lawsuit brought by BJ Services Company. In January 2004, we filed a petition requesting that the United States Supreme Court review and reverse the judgment, which was denied in April 2004. In April 2004, we paid the $107 million judgment amount, including pre- and post-judgment interest, with the funds that had been used for the bond.
Anglo-Dutch (Tenge). On October 24, 2003, a Texas district court jury returned a verdict finding a subsidiary of Halliburton liable to Anglo-Dutch (Tenge) L.L.C. and Anglo-Dutch Petroleum International, Inc. for breaching a confidentiality agreement related to an investment opportunity we considered in the late 1990s in an oilfield in the former Soviet Republic of Kazakhstan. On January 20, 2004, the judge in that case entered judgment against us and our codefendants, Ramco Oil & Gas, Ltd. and Ramco Energy, PLC (collectively, Ramco), jointly and severally, for the total sum of $106 million. A charge in the amount of $77 million was recorded in the third quarter of 2003 related to this matter. In April 2004, we reached a settlement with the plaintiffs and made all payments to the plaintiffs pursuant to the settlement agreement. As a result of the s ettlement, the judgment entered against us has been vacated and the litigation dismissed. The settlement also provided Halliburton total indemnity for contribution claims, if any, of Ramco against Halliburton. After consideration of the settlement and legal costs, we reversed approximately $13 million of our remaining accrual in the first quarter of 2004. In the second quarter of 2004, we recovered the $25 million cash that we posted in lieu of a bond related to this matter, which was included in restricted cash as of March 31, 2004.
Newmont Gold. In July 1998, Newmont Gold, a gold mining and extraction company, filed a lawsuit over the failure of a blower manufactured and supplied to Newmont by Roots, a former division of Dresser Equipment Group. The plaintiff alleges that during the manufacturing process, Roots had reversed the blades on a component of the blower known as the inlet guide vane assembly, resulting in the blower’s failure and the shutdown of the gold extraction mill for a period of approximately one month during 1996. In January 2002, a Nevada trial court granted summary judgment to Roots on all counts and Newmont appealed. In February 2004, the Nevada Supreme Court reversed the summary judgment and remanded the case to the trial court, holding that fact issues existed which would require trial. We believe our exposure is no more than $40 million. We believe t hat we have valid defenses to Newmont’s claims and intend to vigorously defend the matter. As of June 30, 2004, we had not accrued any amounts related to this matter.
Smith International award. In June 2004, a Texas district court jury returned a verdict in our favor in connection with a patent infringement lawsuit we filed against Smith International (Smith). We were awarded $24 million in damages by the jury. Under applicable law the judge has the discretion to enhance the damages to a total amount of up to three times the amount awarded by the jury and to award attorney’s fees and costs. On July 26, 2004, we filed a motion requesting that the judge treble the amount of damages awarded by the jury and add our attorney’s fees and costs as well.
We filed the lawsuit in September 2002 seeking damages for Smith’s infringement of our patented Energy Balanced ™ roller cone drill bit technology. The jury found that Smith’s competing bits willfully infringed three of our patents. The jury also rejected Smith’s claims that the patents are invalid. We had not recorded a gain on this lawsuit as of June 30, 2004 as Smith has appealed the verdict.
Related litigation dealing with claims of infringement of the same technology is pending in courts in Italy and England.
Improper payments reported to the Securities and Exchange Commission. During the second quarter of 2002, we reported to the SEC that one of our foreign subsidiaries operating in Nigeria made improper payments of approximately $2.4 million to entities owned by a Nigerian national who held himself out as a tax consultant, when in fact he was an employee of a local tax authority. The payments were made to obtain favorable tax treatment and clearly violated our Code of Business Conduct and our internal control procedures. The payments were discovered during our audit of the foreign subsidiary. We conducted an investigation assisted by outside legal counsel and, based on the findings of the investigation, we terminated several employees. None of our senior officers were involved. We are cooperating with the
 
  26  

 
SEC in its review of the matter. We took further action to ensure that our foreign subsidiary paid all taxes owed in Nigeria. A preliminary assessment of approximately $4 million was issued by the Nigerian tax authorities in the second quarter of 2003. We are cooperating with the Nigerian tax authorities to determine the total amount due as quickly as possible.
Nigerian joint venture. The SEC has commenced a formal investigation into payments made in connection with the construction and subsequent expansion by TSKJ of a multibillion dollar natural gas liquefaction complex and related facilities at Bonny Island in Rivers State, Nigeria. The United States Department of Justice is also investigating. The SEC and the Department of Justice have been reviewing these matters in light of the requirements of the United States Foreign Corrupt Practices Act. We have produced documents to the SEC both voluntarily and pursuant to a subpoena, and intend to make our employees available to the SEC for testimony. In addition, we understand that A. Jack Stanley, who most recently served as a consultant and chairman of Kellogg Brown & Root, has received a subpoena from the SEC.
TSKJ and other similarly owned entities entered into various contracts to build and expand the liquefied natural gas project for Nigeria LNG Limited, which is owned by the Nigerian National Petroleum Corporation, Shell Gas B.V., Cleag Limited (an affiliate of Total), and Agip International B.V. TSKJ is a private limited liability company registered in Madeira, Portugal whose members are Technip SA of France, Snamprogetti Netherlands B.V., which is an affiliate of ENI SpA of Italy, JGC Corporation of Japan, and Kellogg Brown & Root, each of which owns 25% of the venture.
It has been reported in the French press that the French magistrate has officially placed Jeffrey Tesler, an agent of TSKJ, under investigation for corruption of a foreign public official. In Nigeria, a legislative committee of the National Assembly and the Economic and Financial Crimes Commission, which is organized as part of the executive branch of the government, are also investigating these matters. Our representatives have met with the French magistrate and Nigerian officials and expressed our willingness to cooperate with those investigations.
In June 2004, we terminated all relationships with Mr. Stanley and another consultant and former employee of M.W. Kellogg, Ltd., a joint venture in which Kellogg Brown & Root has a 55% interest. The terminations occurred because of violations of our Code of Business Conduct that allegedly involve the receipt of improper personal benefits in connection with TSKJ's construction of the natural gas liquefaction facility in Nigeria. We understand that the Department of Justice has expanded its investigation to include whether Mr. Stanley may have received payments in connection with bidding practices on certain foreign projects. We also understand that the matters under investigation by the Department of Justice involve parties other than Kellogg Brown & Root and M.W. Kellogg, Ltd. and cover an extended period of time, in some cases significantly before our acquisition of Dresser I ndustries in 1998.
Our investigation of these matters is too preliminary to determine any impact they may have on us. We have engaged outside counsel to investigate any allegations and are cooperating with the United States government's inquiries. There can be no assurance that the government's or our investigation will not conclude that violations of applicable laws have occurred.
As of June 30, 2004, we had not accrued any amounts related to these investigations.
Operations in Iran. We received and responded to an inquiry in mid-2001 from the Office of Foreign Assets Control (OFAC) of the United States Treasury Department with respect to operations in Iran by a Halliburton subsidiary that is incorporated in the Cayman Islands. The OFAC inquiry requested information with respect to compliance with the Iranian Transaction Regulations. These regulations prohibit United States citizens, including United States corporations and other United States business organizations, from engaging in commercial, financial, or trade transactions with Iran, unless authorized by OFAC or exempted by statute. Our 2001 written response to OFAC stated that we believed that we were in full compliance with applicable sanction regulations. In January 2004, we received a follow-up letter from OFAC requesting additional information. We res ponded fully to this request on March 19, 2004. We understand this matter has now been referred by OFAC to the Department of Justice. In July 2004, we
 
  27  

 
received from an Assistant United States Attorney for the Southern District of Texas a grand jury subpoena requesting the production of documents. We intend to cooperate with the government’s investigation. As of June 30, 2004, we had not accrued any amounts related to this investigation.
Separate from the OFAC inquiry, we completed a study in 2003 of our activities in Iran during 2002 and 2003 and concluded that these activities were in full compliance with applicable sanction regulations. These sanction regulations require isolation of entities that conduct activities in Iran from contact with United States citizens or managers of United States companies.
Environmental. We are subject to numerous environmental, legal, and regulatory requirements related to our operations worldwide. In the United States, these laws and regulations include, among others:
-   the Comprehensive Environmental Response, Compensation, and Liability Act;
-   the Resources Conservation and Recovery Act;
-   the Clean Air Act;
-   the Federal Water Pollution Control Act; and
-   the Toxic Substances Control Act.
In addition to the federal laws and regulations, states and other countries where we do business may have numerous environmental, legal, and regulatory requirements by which we must abide. We evaluate and address the environmental impact of our operations by assessing and remediating contaminated properties in order to avoid future liabilities and comply with environmental, legal, and regulatory requirements. On occasion, we are involved in specific environmental litigation and claims, including the remediation of properties we own or have operated as well as efforts to meet or correct compliance-related matters. Our Health, Safety and Environment group has several programs in place to maintain environmental leadership and to prevent the occurrence of environmental contamination.
We do not expect costs related to these remediation requirements to have a material adverse effect on our consolidated financial position or our results of operations. Our accrued liabilities for environmental matters were $38 million as of June 30, 2004 and $31 million as of December 31, 2003. The liability covers numerous properties, and no individual property accounts for more than $5 million of the liability balance. In some instances, we have been named a potentially responsible party by a regulatory agency, but in each of those cases, we do not believe we have any material liability. We have subsidiaries that have been named as potentially responsible parties along with other third parties for 13 federal and state superfund sites for which we have established a liability. As of June 30, 2004, those 13 sites accounted for approximately $9 million of our total $38 million liabilit y.
Letters of credit. In the normal course of business, we have agreements with banks under which approximately $1.2 billion of letters of credit or bank guarantees were outstanding as of June 30, 2004, including $252 million which relate to our joint ventures’ operations.
In the fourth quarter of 2003, we entered into a senior secured master letter of credit facility (Master LC Facility) with a syndicate of banks which covered at least 90% of the face amount of our then existing letters of credit. The Master LC Facility became effective in December 2003. Each bank has permanently waived any right that it had to demand cash collateral as a result of the filing of Chapter 11 proceedings. In addition, at the discretion of the banks involved the Master LC Facility provides for the issuance of new letters of credit, so long as the total facility does not exceed an amount equal to the amount of outstanding letters of credit at closing plus $250 million, or approximately $1.5 billion.
The purpose of the Master LC Facility is to provide an advance for letter of credit draws, if any, as well as to provide collateral for the reimbursement obligations for the letters of credit. In May 2004, we extended the Master LC Facility, and advances under the Master LC Facility will now remain available until the earlier of December 31, 2004 or when an order confirming the proposed plan of reorganization becomes final and nonappealable. At that time, all advances outstanding under the Master LC Facility, if any, will become term loans payable in full on June 30, 2005 and all other letters of credit shall cease to be subject to the terms of the Master LC Facility. As of June 30, 2004 and December 31, 2003, there were no outstanding advances under the Master LC Facility.
 
  28  

 
Liquidated damages. Many of our engineering and construction contracts have milestone due dates that must be met or we may be subject to penalties for liquidated damages if claims are asserted and we were responsible for the delays. These generally relate to specified activities within a project by a set contractual date or achievement of a specified level of output or throughput of a plant we construct. Each contract defines the conditions under which a customer may make a claim for liquidated damages. In most instances, liquidated damages are not asserted by the customer but the potential to do so is used in negotiating claims and closing out the contract. We had not accrued liabilities for $135 million at June 30, 2004 and $243 million at December 31, 2003 of liquidated damages we could incur based upon completing the projects as forecasted. If the April 2004 agreement in principle between Kellogg Brown and Root and Barracuda and Caratinga Leasing Company B.V. were not finalized, based on June 2004 project forecasts, Kellogg Brown & Root could be subject to an additional approximately $159 million in liquidated damages beyond the $85 million of liquidated damages recorded as of June 30, 2004 in the event that the delay in the project is determined to be attributable to us. There can be no assurance that further project delays will not occur.
Other. We are a party to various other legal proceedings. We expense the cost of legal fees as incurred related to these proceedings. We believe any liabilities we may have arising from these proceedings will not be material to our consolidated financial position or results of operations.

Note 15. Accounting for Stock-Based Compensation
We have six stock-based employee compensation plans. We account for those plans under the recognition and measurement principles of Accounting Principles Board Opinion No. 25, “Accounting for Stock Issued to Employees,” and related interpretations. No cost for stock options granted is reflected in net income, as all options granted under our plans have an exercise price equal to the market value of the underlying common stock on the date of grant. In addition, no cost for the Employee Stock Purchase Plan is reflected in net income because it is not considered a compensatory plan.
The fair value of options at the date of grant and the employee stock purchase plan shares were estimated using the Black-Scholes option pricing model. The following table illustrates the effect on net income and income per share if we had applied the fair value recognition provisions of Financial Accounting Standards Board (FASB) Statement of Financial Accounting Standards (SFAS) No. 123, “Accounting for Stock-Based Compensation,” to stock-based employee compensation.

 
 
Three Months
Six Months
 
 
Ended June 30
Ended June 30
   

(Millions of dollars except per share data)
 
2004
2003
2004
2003

 
 
 
 
 
Net income (loss), as reported
 
$
(667
)
$
26
 
$
(732
)
$
69
 
Total stock-based employee compensation
   
 
   
 
   
 
   
 
 
expense determined under fair value
   
 
   
 
   
 
   
 
 
based method for all awards, net of
   
 
   
 
   
 
   
 
 
related tax effects
   
(7
)
 
(7
)
 
(13
)
 
(13
)

 
 
 
 
 
Net income (loss), pro forma
 
$
(674
)
$
19
 
$
(745
)
$
56
 

 
 
 
 
 
 
   
 
   
 
   
 
   
 
 
Basic income (loss) per share:
   
 
   
 
   
 
   
 
 
As reported
 
$
(1.52
)
$
0.06
 
$
(1.67
)
$
0.16
 

 
 
 
 
 
Pro forma
 
$
(1.54
)
$
0.04
 
$
(1.70
)
$
0.13
 

 
 
 
 
 
 
   
 
   
 
   
 
   
 
 
Diluted income (loss) per share:
   
 
   
 
   
 
   
 
 
As reported
 
$
(1.52
)
$
0.06
 
$
(1.67
)
$
0.16
 

 
 
 
 
 
Pro forma
 
$
(1.54
)
$
0.04
 
$
(1.70
)
$
0.12
 

 
 
 
 
 

 
  29  

 
Note 16. Income (Loss) Per Share
Basic income (loss) per share is based on the weighted average number of common shares outstanding during the period. Diluted income (loss) per share includes additional common shares that would have been outstanding if potential common shares, consisting primarily of stock options, with a dilutive effect had been issued. For the three months ended June 30, 2004, we have used the basic weighted average shares in the calculation as the effect of the common stock equivalents would be antidilutive based upon the net loss from continuing operations. The effect of common stock equivalents on basic weighted average shares outstanding was an additional three million shares in the six months ended June 30, 2004 and an additional two million shares in the three and six months ended June 30, 2003. Excluded from the computation of diluted income (loss) per share are options to purchase nine mill ion shares of common stock which were outstanding during the three and six months ended June 30, 2004 and 15 million shares which were outstanding during the three and six months ended June 30, 2003. These options were outstanding during these quarters but were excluded because the option exercise price was greater than the average market price of the common shares. The shares issuable upon conversion of the 3.125% convertible senior notes due 2023 were not included in the computation of diluted income (loss) per share since the conditions for conversion had not been met as of June 30, 2004. Loss per share for discontinued operations and net loss for the six months ended June 30, 2004 were antidilutive, as the control number used to determine whether to include any common stock equivalents in the weighted shares outstanding for the period is income from continuing operations.

Note 17. Income Taxes
Benefit for income taxes of $29 million resulted in an effective tax rate of 36% in the second quarter of 2004, compared to an effective tax rate of 39% in the second quarter of 2003. The tax rate on the loss for the second quarter 2004 was attributable to lower tax benefits on the Barracuda-Caratinga charge partially offset by a reduction of current taxes in foreign jurisdictions.
Provision for income taxes of $20 million resulted in an effective tax rate of 39% in the first six months of 2004, compared to an effective tax rate of 41% in the first six months of 2003.  The tax rate for the first six months of 2004 was attributable to lower tax benefits on the Barracuda-Caratinga charge, partially offset by a reduction of current taxes in foreign jurisdictions.  The tax rate for the first six months of 2003 was mostly the result of the tax effect on the gain from the sale of our Mono Pumps business and loss from the sale of Wellstream.  These transactions included $14 million of realized cumulative translation loss, which is not deductible for tax purposes.

 
  30  

 
Note 18. Retirement Plans
The components of net periodic benefit cost for the three and six months ended June 30, 2004 and June 30, 2003 are as follows:

 
 
Pension Benefits
 
   
 
 
 
Three Months Ended
Other Postretirement
 
 
June 30
Benefits
   

 
 
2004
2003
Three Months Ended
   

 
 
 
United
 
United
 
June 30
           
(Millions of dollars)
 
States
International
States
International
2004
2003
                     
             
Components of net periodic
   
 
   
 
   
 
   
 
   
 
   
 
 
benefit cost:
   
 
   
 
   
 
   
 
   
 
   
 
 
Service cost
 
$
-
 
$
21
 
$
1
 
$
18
 
$
-
 
$
1
 
Interest cost
   
3
   
36
   
2
   
30
   
2
   
3
 
Expected return on plan assets
   
(3
)
 
(40
)
 
(3
)
 
(34
)
 
-
   
-
 
Amortization of prior
   
 
   
 
   
 
   
 
   
 
   
 
 
service cost
   
-
   
-
   
-
   
-
   
(3
)
 
-
 
Settlements/curtailments
   
-
   
-
   
-
   
-
   
-
   
-
 
Recognized actuarial loss
   
1
   
4
   
1
   
5
   
1
   
-
 

 
 
 
 
 
 
 
Net periodic benefit cost
 
$
1
 
$
21
 
$
1
 
$
19
 
$
-
 
$
4
 

 
 
 
 
 
 
 


 
 
Pension Benefits
 
   
 
 
 
Six Months Ended
Other Postretirement
 
 
June 30
Benefits
   

 
 
2004
2003
Six Months Ended
   

 
 
 
United
 
United
 
June 30
           
(Millions of dollars)
 
States
International
States
International
2004
2003
                     
             
Components of net periodic
   
 
   
 
   
 
   
 
   
 
   
 
 
benefit cost:
   
 
   
 
   
 
   
 
   
 
   
 
 
Service cost
 
$
-
 
$
43
 
$
1
 
$
36
 
$
-
 
$
1

 

Interest cost
   
5
   
72
   
5
   
60
   
3
   
6
 
Expected return on plan assets
   
(6
)
 
(81
)
 
(6
)
 
(68
)
 
-
   
-
 
Amortization of prior
   
 
   
 
   
 
   
 
   
 
   
 
 
service cost
   
-
   
-
   
-
   
-
   
(5
)
 
-
 
Settlements/curtailments
   
1
   
-
   
-
   
-
   
-
   
-
 
Recognized actuarial loss
   
2
   
8
   
1
   
9
   
1
   
-
 

 
 
 
 
 
 
 
Net periodic benefit
   
 
   
 
   
 
   
 
   
 
   
 
 
(income) cost
 
$
2
 
$
42
 
$
1
 
$
37
 
$
(1
)
$
7
 

 
 
 
 
 
 
 

We currently expect to contribute approximately $67 million to our pension plans in 2004. As of June 30, 2004, we have contributed $39 million to our plans.
Effective July 1, 2004, we have adopted FAS Staff Position (FSP) 106-2 “Accounting for the Medicare Act,” which is related to our retiree medical plans. We will recognize the impact of the FSP in the third quarter of 2004.

Note 19. New Accounting Pronouncements
On January 1, 2003, we adopted SFAS No. 143, “Accounting for Asset Retirement Obligations,” which addresses the financial accounting and reporting for obligations associated with the retirement of tangible long-lived assets and the associated assets’ retirement costs. SFAS No. 143 requires that the fair
 
  31  

 
value of a liability associated with an asset retirement be recognized in the period in which it is incurred if a reasonable estimate of fair value can be made. The associated retirement costs are capitalized as part of the carrying amount of the long-lived asset and subsequently depreciated over the life of the asset. The adoption of this standard resulted in a charge of $8 million after tax as a cumulative effect of a change in accounting principle. The asset retirement obligations primarily relate to the removal of leasehold improvements upon exiting certain lease arrangements and restoration of land associated with the mining of bentonite. The total liability recorded at adoption and at June 30, 2004 for asset retirement obligations and the related accretion and depreciation expense for all periods presented is immaterial to our consolidated financial position and results of operat ions.
The FASB issued FASB Interpretation No. 46, “Consolidation of Variable Interest Entities, an Interpretation of ARB No. 51” (FIN 46), in January 2003. In December 2003, the FASB issued FIN 46R, a revision which supersedes the original interpretation. We adopted FIN 46R effective January 1, 2004.
FIN 46R requires the consolidation of entities in which a company absorbs a majority of another entity's expected losses, receives a majority of the other entity's expected residual returns, or both, as a result of ownership, contractual, or other financial interests in the other entity. Currently, entities are generally consolidated based upon a controlling financial interest through ownership of a majority voting interest in the entity.
We have identified the following variable interest entities:
-   during the second quarter of 2001, we formed a joint venture, WellDynamics, with Shell in which we held a 50% equity interest and accounted for the investment using the equity method in our Landmark and Other Energy Services segment. The joint venture was established for the further development and deployment of new technologies related to completions and well intervention products and services. In the first quarter of 2004, Halliburton and Shell restructured WellDynamics whereby Halliburton acquired an additional 1% of WellDynamics from Shell, giving Halliburton 51% ownership and control of day-to-day operations. The joint venture is considered a variable interest entity under FIN 46, and we have determined that we are the primary beneficiary of the entity. Beginning in the first quarter of 2004, Wel lDynamics was consolidated and included in our Production Optimization segment. The consolidation of WellDynamics resulted in an increase to our goodwill of $109 million, which was previously carried as equity method goodwill in our investment balance, and an increase in long-term debt of $27 million. There are no assets of WellDynamics that collateralize its obligations and its creditors do not have recourse to Halliburton;
-   during 2001, we formed a joint venture in which we own a 50% equity interest with two unrelated partners, each owning a 25% equity interest. This variable interest entity was formed to construct, operate, and service certain assets for a third party, and was funded with third-party debt. The construction of the assets was completed in the second quarter of 2004, and the operating and service contract related to the assets extends through 2023. The proceeds from the debt financing are being used to construct the assets and will be paid down with cash flows generated during the operation and service phase of the contract with the third party. As of June 30, 2004, the joint venture had total assets of $165 million and total liabilities of $164 million. Our aggregate exposure to loss as a result of our in volvement with this joint venture is limited to our equity investment and subordinated debt of $11 million and any future losses related to the construction and operation of the assets. We are not the primary beneficiary. The joint venture is accounted for under the equity method of accounting in our Engineering and Construction Group segment; and
-   our Engineering and Construction Group is involved in three projects executed through joint ventures to design, build, operate, and maintain roadways for certain government agencies. We have a 25% ownership interest in these joint ventures and account for them
 
  32  

 
under the equity method. These joint ventures are considered variable interest entities as they were initially formed with little equity contributed by the partners. The joint ventures have obtained financing through third parties which is not guaranteed by us. We are not the primary beneficiary of these joint ventures and will, therefore, continue to account for them using the equity method. As of June 30, 2004, these joint ventures had total assets of $1.4 billion and total liabilities of $1.3 billion. Our maximum exposure to loss is limited to our equity investments in and loans to the joint ventures, which totaled $21 million at June 30, 2004, and our share of any future losses to the construction of these roadways.
In May 2003, the Emerging Issues Task Force finalized its Issue No. 00-21 (EITF 00-21), “Revenue Arrangements with Multiple Deliverables,” which addresses certain aspects of the accounting by a vendor for arrangements under which it will perform multiple revenue-generating activities. As a result of our adoption of EITF 00-21 for contracts entered into subsequent to June 30, 2003, we recognize award fees and performance awards for the services portion of our contracts only when awarded by the customer. Award fees and performance awards on the construction portion of our contracts continue to be recognized based on estimates in accordance with the American Institute of Certified Public Accountants Statement of Position 81-1, “Accounting for Performance of Construction-Type and Certain Production-Type Contracts.” The amount of award fees and performance awards deferr ed on government contracts affected by EITF 00-21 in the second quarter of 2004 was immaterial.
 
  33  

 
Item 2. Management’s Discussion and Analysis of Financial Condition and Results of Operations

EXECUTIVE OVERVIEW
During the first six months of 2004, we continued to:
-   make progress on our asbestos and silica settlement;
-   provide a large amount of government services work in the Middle East;
-   experience issues related to our Barracuda-Caratinga project, a large multiyear construction project in Brazil; and
-   address the substantial expected future demands on our funds.
Our operational performance, although disappointing with respect to the Barracuda-Caratinga project, was particularly strong in our oilfield services and government services operations.
Asbestos and silica. Having reached definitive settlements with almost all of our asbestos and silica personal injury claimants, certain of our subsidiaries filed Chapter 11 proceedings on December 16, 2003. A preapproved proposed plan of reorganization was filed as part of the Chapter 11 proceedings. On July 21, 2004, the bankruptcy court entered an order, effective as of July 16, 2004, confirming the proposed plan of reorganization to implement our proposed asbestos and silica settlement. On July 26, 2004, certain of our insurance companies filed a notice of appeal concerning the bankruptcy court’s confirmation. Also on July 26, 2004, the United States District Court for the Western District of Pennsylvania affirmed the confirmation order. On August 3, 2004, certain of our insurance companies filed a motion to vacate the District Court's affirmatin or der in order to protect their appeal rights. If our previously announced agreements in principle with our insurance companies are finalized and approved by the relevant bankruptcy courts, we believe that the insurance companies will dismiss their notice of appeal, that the District Court’s affirmation order will become final and nonappealable, and that the plan of reorganization will become effective. Upon final and nonappealable confirmation of the plan of reorganization, current and future asbestos and silica personal injury claims against Halliburton and its subsidiaries will be channeled into trusts established for the benefit of claimants, thus releasing Halliburton and its affiliates from those claims.
We entered into a settlement with Equitas, the largest insurer of our asbestos and silica claims, during the first quarter of 2004. The settlement calls for Equitas to pay us $575 million, representing approximately 60% of applicable limits of liability that DII Industries had substantial likelihood of recovering from Equitas, provided that our plan of reorganization becomes effective and the current United States Congress does not pass national asbestos litigation reform legislation.
In May 2004, we entered into nonbinding agreements in principle with representatives of the London Market insurance companies that, if implemented, would settle insurance disputes with substantially all the solvent London Market insurance companies for asbestos- and silica-related claims and all other claims under the applicable insurance policies. The agreements in principle are subject to board of directors’ approval of all parties, agreement by all remaining London Market insurance companies, and an order by the bankruptcy court confirming our proposed plan of reorganization that has become final and nonappealable.
We also expect to shortly enter into a nonbinding agreement in principle with our solvent domestic insurance companies that, if implemented, would settle asbestos- and silica-related claims and all other claims under the applicable insurance policies and terminate all the applicable insurance policies. The final settlement agreement with the domestic insurance companies would be subject to board of directors’ approval of all parties, an order by the bankruptcy court approving the final settlement agreement, agreement by Federal-Mogul Products, Inc. (Federal-Mogul) and Cooper Industries, Inc. (Cooper) concerning DII Industries’ rights to access certain of the insurance policies, approval by the Federal-Mogul bankruptcy court of the agreement with Federal-Mogul and Cooper, and an order by the bankruptcy court confirming our proposed plan of reorganization that has become final and nonappealable.
These proposed settlements with our London Market and domestic insurance companies are subject to numerous conditions similar to the conditions of the Equitas settlement, including the condition that the United States Congress does not pass national asbestos litigation reform legislation before January 5, 2005.
 
  34  

 
Under the terms of our announced insurance settlements and proposed insurance settlements, we expect to receive cash proceeds with a present value of approximately $1.4 billion for our asbestos- and silica-related insurance receivables. Our December 31, 2003 estimate of our asbestos- and silica-related insurance receivables already included the charge for the settlement amount under the Equitas agreement reached in January 2004, as well as certain other probable settlements with companies for which we could reasonably estimate the amount of the settlement. In the second quarter of 2004, we reduced the amount recorded as insurance receivables for asbestos- and silica-related liabilities insured by domestic companies, based upon the proposed agreement in principle, resulting in a pretax charge to discontinued operations of approximately $680 million.
At June 30, 2004, the liability related to the 59.5 million shares of Halliburton common stock to be contributed to the trusts was valued at $1.7 billion, an increase of $190 million from December 31, 2003, all of which was recorded during the first quarter of 2004. The increase in value reflected the rise in Halliburton’s stock price during the period.
Government services in the Middle East. Our government services revenue related to Iraq totaled approximately $4 billion during the first half of 2004 and approximately $3.6 billion in 2003. The work we perform includes providing construction and services for, among other things:
-   logistical support to the United States Army, including camp construction, operations and maintenance, food and dining services, and transportation services; and
-   restoration of the Iraqi petroleum industry, including the assessment and repair of the oil infrastructure associated with the Iraqi Southern oilfields.
The accelerated ramp-up in services in a war zone brought with it several challenges, including keeping our people safe, recruiting and retaining qualified personnel, identifying and retaining appropriate subcontractors, establishing the necessary internal control procedures associated with this type of business, and funding the increased working capital demands. We have received and expect to continue to receive heightened media, legislative, and regulatory attention regarding our work in Iraq, including the preliminary results of various audits by the Defense Contract Audit Agency (DCAA) related to our invoicing practices and our self-reporting of possible improper conduct by one or two of our former employees. In the first quarter of 2004, we reviewed our dining facilities and administration centers (DFACs) in our Iraq and Kuwait areas of operation and have billed and continue to b ill for all current DFAC costs. During the second quarter of 2004, we received notice from the DCAA that it is recommending withholding a portion of all our DFAC billings. The amount withheld totaled approximately $203 million as of June 30, 2004. The DCAA is continuing to recommend withholding 19.35% of payments on future DFAC billings relating to subcontracts entered into prior to February 2004.
During 2004, the Army Materiel Command issued mandates that could cause it to withhold 15% from our invoices to be paid after August 15, 2004 until our task orders under the LogCAP contract are definitized. We do not believe the potential 15% withholding will have a significant or sustained impact on our liquidity because the withholding is temporary and ends once the definitization process is complete.
During the second quarter of 2004, the Army Corps of Engineers withheld $57 million of our invoices related to a portion of our Restore Iraqi Oil I (RIO I) contract pending completion of the definitization process. All ten definitization proposals required under this contract have been submitted and two have been finalized. The remaining eight are under review by the DCAA. These withholdings represent the amount invoiced in excess of 85% of the currently estimated amounts. The Army Corps of Engineers also could withhold similar amounts from future invoices under our RIO I contract until our task orders under the RIO I contract are definitized. We do not believe the withholding will have a significant or sustained impact on our liquidity because the withholding is temporary and ends once the definitization process is complete.
Barracuda-Caratinga project. In recent years we have faced issues related to our Barracuda-Caratinga project, a multiyear construction project to build two converted supertankers which will be used as floating production, storage, and offloading units (FPSOs), 32 hydrocarbon production wells, 22 water injection wells, and all subsea flow lines, umbilicals, and risers necessary to connect the underwater wells
 
  35  

 
to the FPSOs. The project will be used to develop the Barracuda and Caratinga crude oilfields, which are located off the coast of Brazil. The project is significantly behind the original schedule and is in a financial loss position. In the first half of 2004, we recorded $407 million in pretax losses, which brings the inception-to-date pretax loss recorded on this project to $762 million. Of this amount, approximately $310 million was recorded in the second quarter of 2004, resulting from a detailed review of the project indicating higher cost estimates, schedule delays, and increased contingencies for the balance of the project. Approximately $97 million was recorded during the first quarter of 2004, resulting from the April 2004 agreement in principle with Petrobras, as well as adjustments to our estimates of costs expected to be incurred to complete the project.
Financing activities. The anticipated cash contribution to the asbestos and silica trusts later this year, the increased work in Iraq, and potential additional delays of certain billings related to work in Iraq have required us to raise substantial funds and could require us to raise additional funds in order to meet our current and potential future liabilities and working capital requirements. On January 26, 2004, we issued $500 million aggregate principal amount of senior notes due 2007 bearing interest at a floating rate equal to three-month LIBOR plus 0.75%, payable quarterly. In addition, related to the prepackaged Chapter 11 filing, we entered into the following facilities, all of which are currently undrawn:
-   a secured master letter of credit facility intended to ensure that existing letters of credit supporting our contracts remain in place during the Chapter 11 proceedings, which allows advances until December 31, 2004 or the exit date of our Chapter 11 proceedings, with repayments due June 30, 2005;
-   a secured $700 million three-year revolving credit facility for general working capital purposes which matures in October 2006; and
-   a secured $500 million 364-day revolving credit facility for general working capital purposes which matures in July 2005.
We have also received $268 million under our United States Energy Services Group (ESG) accounts receivable securitization facility as of June 30, 2004 and sold approximately $50 million of government receivables as of June 30, 2004. In addition, as early as January 2005, we may receive approximately $981 million of the funds that would be provided by Equitas and other insurance companies based on the settlements described above. We are executing programs to improve our working capital and to limit our spending on capital projects to those critical to serving our customers. We continue to maintain our investment grade credit ratings and believe we have sufficient cash and financing capacity to fund our asbestos and silica settlement obligations later this year and continue to grow our business.
Business focus. The outlook for our business is improving, with solid second quarter of 2004 results from all ESG business segments. As compared to the second quarter of 2003, ESG revenue increased in most geographic areas during the second quarter of 2004. Our ESG business has a strong correlation to oil and gas prices and worldwide rig activity. Oil prices increased approximately 32% from the prior year quarter and gas prices increased approximately 8%. Except for the Gulf of Mexico offshore rig count which continues to decline due to maturation of the market, the United States land and international land and offshore rig counts increased substantially from the prior year quarter. Our government services operating income has increased 40% year-over-year in our Engineering and Construction Group, but is expected to be lower on a comparative basis in the sec ond half of 2004. The two-year $1.2 billion contract for the Repair and Continuity Operations of Iraq Oil Infrastructure, South (formerly RIO II), or PCO Oil South, and the five-year $1.5 billion military support contract offset a decline in work under RIO I, which is a more profitable contract.
Following is a more detailed discussion of each of these subjects.

Asbestos and Silica Obligations and Insurance Recoveries
Prepackaged Chapter 11 proceedings. DII Industries, Kellogg Brown & Root, and six other subsidiaries filed Chapter 11 proceedings on December 16, 2003 in bankruptcy court in Pittsburgh,
 
  36  

 
Pennsylvania. With the filing of the Chapter 11 proceedings, all asbestos and silica personal injury claims and related lawsuits against Halliburton and our affected subsidiaries were stayed. See Note 13 for more information.
Our subsidiaries sought Chapter 11 protection because Sections 524(g) and 105 of the Bankruptcy Code may be used to discharge current and future asbestos and silica personal injury claims against us and our subsidiaries. Upon final and nonappealable confirmation of the plan of reorganization, current and future asbestos and silica personal injury claims against us and our affiliates will be channeled into trusts established for the benefit of claimants under Sections 524(g) and 105 of the Bankruptcy Code, thus releasing Halliburton and its affiliates from those claims. The plan of reorganization will become effective after the affirmation by the United States District Court of the confirmation order of the bankruptcy court becomes final and nonappealable. The affirmation will be final and nonappealable 30 days after entry of the order of affirmation if no appeals are filed or, if appe als are filed, once the appeals are withdrawn by those appealing or disposed of by an appeals court.
A prepackaged Chapter 11 proceeding is one in which a debtor seeks approval of a plan of reorganization from affected creditors before filing for Chapter 11 protection. Prior to proceeding with the Chapter 11 filing, our affected subsidiaries solicited acceptances to a proposed plan of reorganization from known present asbestos and silica claimants. In the fourth quarter of 2003, valid votes were received from approximately 364,000 asbestos claimants and approximately 21,000 silica claimants, representing substantially all known claimants. Of the votes validly cast, over 98% of voting asbestos claimants and over 99% of voting silica claimants voted to accept the proposed plan of reorganization, meeting the voting requirements of Chapter 11 of the Bankruptcy Code for approval of the proposed plan. The preapproved proposed plan of reorganization was filed as part of the Chapter 11 proce edings.
On July 21, 2004, the bankruptcy court entered an order, effective as of July 16, 2004, confirming the proposed plan of reorganization to implement our proposed asbestos and silica settlement. On July 26, 2004, certain of our insurance companies filed a notice of appeal concerning the bankruptcy court’s confirmation. Also on July 26, 2004, the United States District Court for the Western District of Pennsylvania affirmed the confirmation order. On August 3, 2004, certain of our insurance companies filed a motion to vacate the District Court's affirmatin order in order to protect their appeal rights. If our previously announced agreements in principle with our insurance companies are finalized and approved by the relevant bankruptcy courts, we believe that the insurance companies will dismiss their notice of appeal, that the District Court’s affirmation order will become final and nonappealable, and that the plan of reorganization will become effective.
The proposed plan of reorganization, which is consistent with the definitive settlement agreements reached with our asbestos and silica personal injury claimants in early 2003, provides that, if and when an order confirming the proposed plan of reorganization becomes final and nonappealable, the following will be contributed to trusts for the benefit of current and future asbestos and silica personal injury claimants:
-   up to approximately $2.3 billion in cash;
-   59.5 million shares of Halliburton common stock;
-   a one-year non-interest-bearing note of $31 million for the benefit of asbestos claimants;
-   a silica note with an initial payment into a silica trust of $15 million. Subsequently, the note provides that we will contribute an amount to the silica trust balance at the end of each year for the next 30 years to bring the silica trust balance to $15 million, $10 million, or $5 million based upon a formula which uses average yearly disbursements from the trust to determine that amount. The note also provides for an extension of the note for 20 additional years under certain circumstances. We have estimated the amount of this note to be approximately $21 million. We will periodically reassess our valuation of this note based upon our projections of the amounts we believe we will be required to fund into the silica trust; and
-   insurance proceeds, if any, between $2.3 billion and $3.0 billion received by DII Industries and Kellogg Brown & Root. However, if the proposed settlements with our insurance companies are completed on the terms announced or proposed, insurance recoveries will not exceed $2.3 billion.
 
  37  

 
We intend to fund the trusts 30 days after the affirmation by the United States District Court becomes final and nonappealable, but no earlier than October 29, 2004, which is the earliest date the cash amount to be funded will be finalized.
In connection with reaching an agreement with representatives of asbestos and silica claimants to limit the cash required to settle pending claims to $2.775 billion, DII Industries paid $311 million to the claimants in December 2003. We also agreed to guarantee the payment of certain claims, and, in accordance with settlement agreements, we made additional payments of $119 million, plus an additional $4 million in lieu of interest, in June 2004. We expect to pay an additional approximately $50 million in pending claims under these settlement agreements 30 days after the proposed plan of reorganization becomes final and nonappealable. We may not be entitled to reimbursement for these payments if the proposed plan of reorganization does not become effective in accordance with its terms.
Our proposed plan of reorganization calls for a portion of our total asbestos and silica liability to be settled by contributing 59.5 million shares of Halliburton common stock into the trusts. We will adjust our asbestos and silica liability related to the shares if the average value of Halliburton common stock for the five days immediately prior to and including the end of each fiscal quarter has increased by 5% or more from the most recent valuation of the shares. At June 30, 2004, the liability was valued at $1.7 billion, an increase of $190 million from December 31, 2003, all of which was recorded during the first quarter of 2004. The value of the shares to be contributed was classified as a long-term liability on our consolidated balance sheets, and the shares were not included in our calculation of basic or diluted earnings per share. If the shares had been included in the calc ulation as of the beginning of 2004, our diluted earnings per share from continuing operations for the six months ended June 30, 2004 would have been reduced by $0.01 and for the three months ended June 30, 2004 would have been antidilutive. When and if we receive final and nonappealable confirmation of our proposed plan of reorganization, we will:
-   increase or decrease our asbestos and silica liability to value the 59.5 million shares of Halliburton common stock based on the value of Halliburton stock on the date of final and nonappealable confirmation of our proposed plan of reorganization;
-   reclassify from a long-term liability to shareholders’ equity the final value of the 59.5 million shares of Halliburton common stock; and
-   include the 59.5 million shares in our calculations of earnings per share on a prospective basis.
We understand that the United States Congress may consider adopting legislation that would establish a national trust fund as the exclusive means for recovery for asbestos-related disease. We are uncertain as to what contributions we would be required to make to a national trust, if any, although it is possible that they could be substantial and that they could continue for several years. Our level of participation in and contribution to a national trust could be greater or less than it otherwise would have been as a result of having subsidiaries that have filed Chapter 11 proceedings due to asbestos liability.
Recent insurance developments. In January 2004, we reached a comprehensive agreement with Equitas to settle our insurance claims against certain underwriters at Lloyd's of London, reinsured by Equitas. The settlement, if all conditions precedent are satisfied, will resolve all asbestos-related claims made against Lloyd's underwriters by us and by each of our subsidiary and affiliated companies, including DII Industries, Kellogg Brown & Root, and their subsidiaries that have filed Chapter 11 proceedings as part of our proposed settlement. Provided that there is final and nonappealable confirmation of the plan of reorganization in the Chapter 11 proceedings and the current United States Congress does not pass national asbestos litigation reform legislation before January 5, 2005, Equitas will pay us $575 million, representing approximately 60% of the appli cable limits of liability that we believe DII Industries had substantial likelihood of recovering from Equitas. The first payment of $500 million, which is classified as a current receivable as of June 30, 2004, will occur within 15 working days of the later of January 5, 2005 or the date on which the order of the bankruptcy court confirming DII Industries' plan of reorganization becomes final and nonappealable. A second payment of $75 million will be made 18 months after the first payment.
 
  38  

 
In May 2004, we entered into nonbinding agreements in principle with representatives of the London Market insurance companies that, if implemented, would settle insurance disputes with substantially all the solvent London Market insurance companies for asbestos- and silica-related claims and all other claims under the applicable insurance policies. The agreements in principle with the London Market insurance companies are subject to board of directors’ approval of all parties, agreement by all remaining London Market insurance companies, and an order by the bankruptcy court confirming our proposed plan of reorganization that has become final and nonappealable. Currently, we expect to receive cash payments during the years of 2005 through 2009.
We also expect to shortly enter into a nonbinding agreement in principle with our solvent domestic insurance companies that, if implemented, would settle asbestos- and silica-related claims and all other claims under the applicable insurance policies and terminate all the applicable insurance policies. The final settlement agreement with the domestic insurance companies would be subject to board of directors’ approval of all parties, an order by the bankruptcy court approving the final settlement agreement, agreement by Federal-Mogul and Cooper concerning DII Industries’ rights to access certain of the insurance policies, approval by the Federal-Mogul bankruptcy court of the agreement with Federal-Mogul and Cooper, and an order by the bankruptcy court confirming our proposed plan of reorganization that has become final and nonappealable.
These proposed settlements with our insurance companies are subject to numerous conditions. Although we are working toward implementation of these proposed settlements, there can be no assurance that the transactions contemplated by these agreements in principle can be completed on the terms announced.
Under the terms of our announced insurance settlements and proposed insurance settlements, we expect to receive cash proceeds with a nominal amount of $1.5 billion and a present value of approximately $1.4 billion for our asbestos- and silica-related insurance receivables. The present value was determined by discounting the expected future cash payments with a discount rate implicit in the settlements which is approximately 5.5% related to the domestic insurance companies. This discount will be accreted as interest income (classified as discontinued operations) over the life of the expected future cash payments beginning in the third quarter of 2004.
Our December 31, 2003 estimate of our asbestos- and silica-related insurance receivables already included the charge for the settlement amount under the Equitas agreement reached in January 2004, as well as certain other probable settlements with companies for which we could reasonably estimate the amount of the settlement. In the second quarter of 2004, we reduced the amount recorded as insurance receivables for asbestos- and silica-related liabilities insured by domestic companies based upon the proposed agreement in principle, resulting in a pretax charge to discontinued operations of approximately $680 million.

United States Government Contract Work
We provide substantial work under our government contracts business to the United States Department of Defense and other governmental agencies, including worldwide United States Army logistics contracts, known as LogCAP, and contracts to rebuild Iraq’s petroleum industry, known as RIO I and PCO Oil South. Our government services revenue related to Iraq totaled approximately $1.7 billion and $4 billion for the three and six months ended June 30, 2004. Our units operating in Iraq and elsewhere under government contracts such as LogCAP, RIO I, and PCO Oil South consistently review the amounts charged and the services performed under these contracts. Our operations under these contracts are also regularly reviewed and audited by the Defense Contract Audit Agency (DCAA) and other governmental agencies. When issues are found during the governmental agency audit process, these issues ar e typically discussed and reviewed with us in order to reach a resolution.
The results of a preliminary audit by the DCAA in December 2003 alleged that we may have overcharged the Department of Defense by $61 million in importing fuel into Iraq. After a review, the Army Corps of Engineers, which is our client and oversees the project, concluded that we obtained a fair
 
  39  

 
price for the fuel. However, Department of Defense officials thereafter referred the matter to the agency’s inspector general, which we understand has commenced an investigation.
We have had inquiries in the past by the DCAA and the civil fraud division of the United States Department of Justice into possible overcharges for work performed during 1996 through 2000 under a contract in the Balkans, which inquiry has not yet been completed by the Department of Justice. Based on an internal investigation, we credited our customer approximately $2 million during 2000 and 2001 related to our work in the Balkans as a result of billings for which support was not readily available. We believe that the preliminary Department of Justice inquiry relates to potential overcharges in connection with a part of the Balkans contract under which approximately $100 million in work was done. The Department of Justice has not alleged any overcharges, and we believe that any allegation of overcharges would be without merit.
On January 22, 2004, we announced the identification by our internal audit function of a potential overbilling of approximately $6 million by one of our subcontractors under the LogCAP contract in Iraq for services performed during 2003. In accordance with our policy and government regulation, the potential overcharge was reported to the Department of Defense Inspector General’s office as well as to our customer, the Army Materiel Command. On January 23, 2004, we issued a check in the amount of $6 million to the Army Materiel Command to cover that potential overbilling while we conducted our own investigation into the matter. Later in the first quarter of 2004, we determined that the amount of overbilling was $4 million and the subcontractor billing should have been $2 million for the services provided. As a result, we have processed payment for $2 million and have billed our cus tomer that amount. We are continuing to investigate whether third-party subcontractors paid, or attempted to pay, one or two of our former employees in connection with the billing.
We understand that the United States Department of Justice and an Assistant United States Attorney based in Illinois are investigating some of these matters. We also understand that former employees of KBR have received subpoenas and have given or may give grand jury testimony relating to some of these matters. If criminal wrongdoing were found, criminal penalties could range up to the greater of $500,000 in fines per count for a corporation, or twice the gross pecuniary gain or loss.
During 2003, the DCAA raised issues relating to our invoicing to the Army Materiel Command for food services for soldiers and supporting civilian personnel in Iraq and Kuwait. We believe the issues raised by the DCAA relate to the difference between the number of troops the Army Materiel Command directed KBR to support and the number of soldiers actually served at dining facilities for United States troops and supporting civilian personnel in Iraq and Kuwait. In the first quarter of 2004, we reviewed our DFACs in our Iraq and Kuwait areas of operation and have billed and continue to bill for all current DFAC costs. During the second quarter of 2004, we received notice from the DCAA that it is recommending withholding a portion of all our DFAC billings. The amount withheld totaled approximately $203 million as of June 30, 2004. The DCAA is continuing to recommend withholding 19.35% of payments on future DFAC billings relating to subcontracts entered into prior to February 2004. We are negotiating with our customer, the Army Materiel Command, and the DCAA in an attempt to settle these issues.
During 2004, the Army Materiel Command issued mandates that could cause it to withhold 15% from our invoices to be paid after August 15, 2004 until our task orders under the LogCAP contract are definitized. We do not believe the potential 15% withholding will have a significant or sustained impact on our liquidity because the withholding is temporary and ends once the definitization process is complete.
During the second quarter of 2004, the Army Corps of Engineers withheld $57 million of our invoices related to a portion of our RIO I contract pending completion of the definitization process. All ten definitization proposals required under this contract have been submitted and two have been negotiated. The remaining eight are in DCAA audit. These withholdings represent the amount invoiced in excess of 85% of the currently estimated amounts. The Army Corps of Engineers also could withhold similar amounts from future invoices under our RIO I contract until our task orders under the RIO I contract are definitized. We do not believe the withholding will have a significant or sustained impact on our liquidity because the withholding is temporary and ends once the definitization process is complete.
 
  40  

 
Barracuda-Caratinga Project
In June 2000, Kellogg Brown & Root, Inc. entered into a contract with Barracuda & Caratinga Leasing Company B.V., the project owner, to develop the Barracuda and Caratinga crude oilfields, which are located off the coast of Brazil. The construction manager and project owner's representative is Petrobras, the Brazilian national oil company. When completed, the project will consist of two converted supertankers, Barracuda and Caratinga, which will be used as floating production, storage, and offloading units, commonly referred to as FPSOs. In addition, there will be 32 hydrocarbon production wells, 22 water injection wells, and all subsea flow lines, umbilicals, and risers necessary to connect the underwater wells to the FPSOs. The original completion date for the Barracuda vessel was December 2003, and the original completion date for the Caratinga vessel was April 2004. The pr oject is significantly behind the original schedule, due in large part to change orders from the project owner, and is in a financial loss position. We expect that the Barracuda vessel will likely be completed by June 2005, and the Caratinga vessel will likely be completed by November 2005. However, there can be no assurance that further delays will not occur.
Our performance under the contract is secured by:
-   performance letters of credit, which together have available credit of approximately $272 million as of June 30, 2004 and represent approximately 10% of the contract amount, as amended to date by change orders;
-   retainage letters of credit, which together have available credit of approximately $170 million as of June 30, 2004 and which will increase in order to continue to represent 10% of the cumulative cash amounts paid to us; and
-   a guarantee of KBR’s performance under the agreement by Halliburton Company in favor of the project owner.
In early April 2004, KBR and Petrobras, on behalf of the project owner, entered into a nonbinding agreement in principle. The April 2004 agreement in principle is the basis for settlement of the various claims between the parties and would amend existing agreements. Implementation of the agreement in principle requires final approval of the Board of Directors of Petrobras and Halliburton, the project lenders, and possibly the bankruptcy court that confirmed our proposed plan of reorganization. Discussions among all parties, including the project lenders, are underway. The April 2004 agreement in principle provides for:
-   the release of all claims of all parties that arise prior to the effective date of a final definitive agreement;
-   the payment to us of $79 million as a result of change orders for remaining claims;
-   payment by Petrobras of any value added taxes on the project, except for $8 million which has been paid by us;
-   the assumption by Petrobras of certain work under the original contract;
-   the repayment on December 7, 2004 by KBR of a portion of $300 million of advance payments, without interest; and
-   an extension of time to the original completion dates that average approximately 18 months.
While negotiations are proceeding to reach a final agreement based on the provisions of the April 2004 agreement in principle, there can be no guarantee that an agreement will be achieved.
In the first quarter of 2004, we recorded a charge of $97 million resulting from the April 2004 agreement in principle with Petrobras, as well as adjustments to our estimates of costs expected to be incurred to complete the project. In June 2004, we recorded additional operating losses on our Barracuda-Caratinga project of approximately $310 million. The additional charge resulted from a detailed review of the project indicating higher cost estimates, schedule delays, and increased contingencies for the balance of the project until completion. Specifically, in the second quarter, with the integration phase of the Barracuda vessel we experienced a significant reduction in productivity and rework required from the vessel conversion. We have taken steps to mobilize more resources including specialized management
 
  41  

 
personnel in both Houston and South America to oversee the final stages of the project. We have conducted additional cost and schedule reviews of the remaining project activities, and we have initiated several work process changes in an attempt to expedite work on the project.
As of June 30, 2004:
-   the project was approximately 87% complete;
-   we have recorded an inception-to-date pretax loss of $762 million related to the project, of which $310 million was recorded in the second quarter of 2004; $97 million was recorded in the first quarter of 2004; $238 million was recorded in 2003 ($55 million during the first quarter of 2003, $173 million during the second quarter of 2003 and $10 million in the fourth quarter of 2003); and $117 million was recorded in 2002;
-   the losses recorded include $85 million in liquidated damages; and
-   the probable unapproved claims were reduced from $114 million at December 31, 2003 to zero based upon the April 2004 agreement in principle.
Default provisions. In the event that we were determined to be in default under the contract, and if the project was not completed by us as a result of our default, the project owner may seek direct damages. Those damages could include completion costs in excess of the contract price and interest on borrowed funds, but would exclude consequential damages. The total damages could be up to $500 million plus the return of up to $300 million in advance payments previously received by us to the extent they have not been repaid. A termination of the contract by the project owner could have a material adverse effect on our financial condition and results of operations.
Cash flow considerations. The project owner has procured project finance funding obligations from various lenders to finance the payments due to us under the contract. In addition, the project financing includes borrowing capacity in excess of the original contract amount.
Under the loan documents, the availability date for loan draws expired December 1, 2003 and, therefore, the project owner drew down all remaining available funds on that date. As a condition to the draw-down of the remaining funds, the project owner was required to escrow the funds for the exclusive use of paying project costs. The availability of the escrowed funds can be suspended by the lenders if applicable conditions are not met. With limited exceptions, these funds may not be paid to Petrobras or its subsidiary, which is funding the drilling costs of the project, until all amounts due to us, including amounts due for the change orders as agreed in the April 2004 agreement in principle, are liquidated and paid. While this potentially reduces the risk that the funds would not be available for payment to us, we are not party to the arrangement between the lenders and the project ow ner and can give no assurance that there will be adequate funding to cover current or future claims and change orders.
We have now begun to fund operating cash shortfalls on the project and are obligated to fund total shortages over the remaining project life. That funding level assumes that, pursuant to amended project agreements implementing the April 2004 agreement in principle, neither we nor the project owner recover additional claims against the other. Estimated cash flows relating to the losses are as follows:

(Millions of dollars)
 
 

 
 
Amount funded through June 30, 2004
 
$
249
 
Amount to be funded during the remainder of 2004,
   
 
 
including repayment of a portion of $300
   
 
 
million advance payments
   
342
 
Amount to be funded during 2005
   
171
 

 
 
Total cash shortfalls
 
$
762
 

 
 

LIQUIDITY AND CAPITAL RESOURCES
We ended the second quarter of 2004 with cash and equivalents of $2.2 billion compared to $1.8 billion at December 31, 2003.
 
  42  

 
Significant uses of cash. Our liquidity and cash balance during the first half of 2004 have been significantly affected by our government services work in Iraq. Our working capital requirements for our Iraq-related work, excluding cash and equivalents, were approximately $1.1 billion at June 30, 2004. We expect a general decline in our working capital requirements during the second half of the year, primarily due to the transfer of the civilian fuel delivery work to the Defense Energy Support Center, the completion of the RIO I project, and the leveling off of the LogCAP project work after the initial ramp-up in 2003.
See “Executive Overview - United States Government Contract Work” above for cash flow timing issues related to our United States government work.
In connection with reaching an agreement with representatives of asbestos and silica claimants to limit the cash required to settle pending claims to $2.775 billion, DII Industries paid $311 million to the claimants in December 2003. At that time, we also agreed to guarantee the payment of certain claims, and, in accordance with settlement agreements, we made additional payments of $119 million, plus an additional $4 million in lieu of interest, in June 2004. We expect to pay an additional approximately $50 million in pending claims under these settlement agreements 30 days after the proposed plan of reorganization becomes final and nonappealable. We may not be entitled to reimbursement for these payments if the proposed plan of reorganization does not become effective in accordance with its terms.
Capital expenditures of $284 million in the six months ended June 30, 2004 were 24% higher than in the six months ended June 30, 2003. Capital spending in the first six months of 2004 continued to be primarily directed to the Energy Services Group for production optimization, drilling and formation evaluation, and manufacturing capacity. We expect capital spending to continue at approximately this rate throughout the year. We paid $110 million in dividends to our shareholders in the first six months of 2004 and $109 million in the first six months of 2003.
During 2004, we had significant developments on two legal matters: BJ Services Company patent litigation and Anglo-Dutch (Tenge). See Note 14 to the condensed consolidated financial statements for more information. In April 2004, we paid the $107 million judgment amount in the BJ Services patent litigation, including pre- and post-judgment interest with the funds that had been used to post the bond in the case. In April 2004, we also reached a settlement with the plaintiffs in the Anglo-Dutch litigation and made all payments pursuant to the settlement agreement. During the second quarter of 2004, we recovered the $25 million cash in lieu of bond deposit for the Anglo-Dutch litigation formerly included in restricted cash.
See “Executive Overview - Barracuda-Caratinga Project: Cash flow considerations” above for anticipated timing of cash flow items related to the Barracuda-Caratinga project.
Significant sources of cash. Our operations provided approximately $180 million in cash flow in the first six months of 2004. In addition, we received $20 million from the sale of our remaining shares of National Oilwell, Inc.
In January 2004, we issued senior notes due 2007 totaling $500 million, which will primarily be used to fund the asbestos and silica liability settlement. Our combined short-term notes payable and long-term debt was 70% of total capitalization at June 30, 2004 and 58% of total capitalization at December 31, 2003.
Other sources of cash. In May 2004, Kellogg Brown & Root Services, Inc. entered into an agreement to sell, assign, and transfer its entire title and interest in specified accounts receivable to a third party. The face value of the receivables sold to the third party is reflected as a reduction of accounts receivable in our condensed consolidated balance sheets. The amount of receivables which can be sold under the facility varies based on the amount of eligible KBR receivables at any given time and other factors. However, each receivable sold pursuant to this agreement must have a net face value (as defined in this agreement) of at least $500,000 and the maximum amount that may be outstanding under this agreement at any given time is $650 million. The total amount outstanding under this agreement as of June 30, 2004 was approximately $50 million.< /DIV>
 
  43  

 
In June 2004, we sold undivided interests totaling $268 million under our Energy Services Group securitization facility. See “Off Balance Sheet Risk” below for further discussion.
Future sources of cash. We have available to us significant sources of cash in the near term should we need them.
Asbestos and silica liability financing. In the fourth quarter of 2003, we entered into a secured $700 million three-year revolving credit facility for general working capital purposes. In July 2004, we entered into an additional secured $500 million 364-day revolving credit facility for general working capital purposes with terms substantially similar to our $700 million revolving credit facility. At this time, both of these facilities remain undrawn.
Asbestos and silica settlements with insurance companies. In January 2004, we reached a comprehensive agreement with Equitas to settle our insurance claims against certain underwriters at Lloyd’s of London, reinsured by Equitas, for asbestos- and silica-related claims and all other claims under the applicable insurance policies.
In May 2004, we entered into nonbinding agreements in principle with representatives of the London Market insurance companies that, if implemented, would settle insurance disputes with substantially all the solvent London Market insurance companies for asbestos- and silica-related claims and all other claims under the applicable insurance policies.
We also expect to shortly enter into a nonbinding agreement in principle with our solvent domestic insurance companies that, if implemented, would settle asbestos- and silica-related claims and all other claims under the applicable insurance policies and terminate all the applicable insurance policies.
These proposed settlements with our London Market and domestic insurance companies are subject to numerous conditions, similar to the conditions of the Equitas settlement, including the condition that the United States Congress does not pass national asbestos litigation reform legislation before January 5, 2005.
Under the terms of our announced insurance settlements and proposed insurance settlements, we expect to receive cash proceeds with a present value of approximately $1.4 billion for our asbestos- and silica-related insurance receivables.
See “Executive Overview - Asbestos and Silica Obligations and Insurance Recoveries” above for a discussion regarding the timing of payments related to these settlements.

BUSINESS ENVIRONMENT AND RESULTS OF OPERATIONS

We currently operate in over 100 countries throughout the world, providing a comprehensive range of discrete and integrated products and services to the energy industry and to other industrial and governmental customers. The majority of our consolidated revenues are derived from the sale of services and products, including engineering and construction activities. We sell services and products primarily to major, independent, and national oil and gas companies and the United States Government. These products and services are used throughout the energy industry from the earliest phases of exploration, development, and production of oil and gas resources through refining, processing, and marketing. These products and services are also used by the United States Army Materiel Command for logistical support of troops and the reconstruction of the Iraqi oil industry. Our five business segmen ts are organized around how we manage the business: Drilling and Formation Evaluation, Fluids, Production Optimization, Landmark and Other Energy Services, and the Engineering and Construction Group. We sometimes refer to the combination of our Drilling and Formation Evaluation, Fluids, Production Optimization, and Landmark and Other Energy Services segments as the Energy Services Group.
The industries we serve are highly competitive with many substantial competitors for each segment. In the first half of 2004, based upon the location of the services provided and products sold, 26% of our total revenue was from the United States and 27% was from Iraq. In the first half of 2003, 33% of our total revenue was from the United States and 11% of our total revenue was from the United Kingdom. Revenue from Iraq in the first half of 2003 was less than 10% of our total revenue. No other country
 
  44  

 
accounted for more than 10% of our revenue during these periods. Unsettled political conditions, social unrest, acts of terrorism, force majeure, war or other armed conflict, expropriation or other governmental actions, inflation, exchange controls, or currency devaluation may result in increased business risk in any one country. We believe the geographic diversification of our business activities reduces the risk that loss of business in any international country would be material to our consolidated results of operations.
Halliburton Company
Activity levels within our business segments are significantly impacted by the following:
-   spending on upstream exploration, development, and production programs by major, independent, and national oil and gas companies;
-   capital expenditures for downstream refining, processing, petrochemical, and marketing facilities by major, independent, and national oil and gas companies;
-   military action by the United States; and
-   government spending levels.
Also impacting our activity is the status of the global economy, which indirectly impacts oil and gas consumption, demand for petrochemical products, and investment in infrastructure projects.
Energy Services Group
Some of the more significant barometers of current and future spending levels of oil and gas companies are oil and gas prices, exploration and production expenditures by international and national oil companies, the world economy, and global stability, which together drive worldwide drilling activity. Our Energy Services Group financial performance is significantly affected by oil and gas prices and worldwide rig activity, which are summarized in the following tables. When these increase, it generally means increased work for our businesses. The table below presents average oil and gas prices.

 
 
Three Months Ended
 
 
 
June 30
Year Ended
   

Average Oil and Gas Prices
 
2004
2003
2003

 
 
 
 
West Texas Intermediate
   
 
   
 
   
 
 
oil prices (dollars per barrel)
 
$
38.34
 
$
29.16
 
$
31.14
 
Henry Hub gas prices (dollars per
   
 
   
 
   
 
 
million cubic feet)
 
$
6.08
 
$
5.63
 
$
5.63
 

 
 
 
 

Our customers’ cash flow, in many instances, depends upon the revenue they generate from the sale of oil and gas. With higher prices, they may have more cash flow, which usually translates into higher exploration and production budgets. Sustained higher prices may also mean that oil and gas exploration in marginal areas can become attractive, so our customers may consider investing in such properties when prices are high. The opposite is true for lower oil and gas prices.
As of the second quarter of 2004, oil prices have continued their upward trend due to low petroleum inventory levels in the United States and Organization for Economic Cooperation and Development countries, geopolitical risk premiums resulting from terrorist attacks in the Middle East, strike disruptions in Norway and Nigeria, and uncertainty about the future of Russia’s capability of supplying the international marketplace. Natural gas prices have remained relatively high. Even though inventories of natural gas appear normal, strong demand for natural gas coupled with high petroleum prices has lifted natural gas prices.
The quarterly and yearly average rotary rig counts based on the Baker Hughes Incorporated rig count information are as follows:
 
  45  

 

 
 
Three Months Ended
Six Months Ended
 
 
June 30
June 30
   

Average Rig Counts
 
2004
2003
2004
2003

 



Land vs. Offshore
 
 
 
 
 

 
 
 
 
 
United States:
   
 
   
 
   
 
   
 
 
Land
   
1,070
   
919
   
1,045
   
856
 
Offshore
   
94
   
109
   
96
   
109
 

 
 
 
 
 
Total
   
1,164
   
1,028
   
1,141
   
965
 

 
 
 
 
 
Canada:
   
 
   
 
   
 
   
 
 
Land
   
199
   
199
   
361
   
345
 
Offshore
   
3
   
4
   
4
   
3
 

 
 
 
 
 
Total
   
202
   
203
   
365
   
348
 

 
 
 
 
 
International (excluding Canada):
   
 
   
 
   
 
   
 
 
Land
   
586
   
534
   
574
   
533
 
Offshore
   
251
   
231
   
243
   
222
 

 
 
 
 
 
Total
   
837
   
765
   
817
   
755
 

 
 
 
 
 
Worldwide total
   
2,203
   
1,996
   
2,323
   
2,068
 

 
 
 
 
 
Land total
   
1,855
   
1,652
   
1,980
   
1,734
 

 
 
 
 
 
Offshore total
   
348
   
344
   
343
   
334
 

 
 
 
 
 


 
 
Three Months Ended
Six Months Ended
 
 
June 30
June 30
   

Average Rig Counts
 
2004
2003
2004
2003

 



Oil vs. Gas
 
 
 
 
 

 
 
 
 
 
United States:
   
 
   
 
   
 
   
 
 
Oil
   
158
   
168
   
156
   
160
 
Gas
   
1,006
   
860
   
985
   
805
 

 
 
 
 
 
Total
   
1,164
   
1,028
   
1,141
   
965
 

 
 
 
 
 
Canada: *
   
202
   
203
   
365
   
348
 
International (excluding Canada):
   
 
   
 
   
 
   
 
 
Oil
   
625
   
558
   
611
   
549
 
Gas
   
212
   
207
   
206
   
206
 

 
 
 
 
 
Total
   
837
   
765
   
817
   
755
 

 
 
 
 
 
Worldwide total
   
2,203
   
1,996
   
2,323
   
2,068
 

 
 
 
 
 
* Canadian rig counts by oil and gas were not available.

Most of our work in the Energy Services Group closely tracks the number of active rigs. As rig count increases or decreases, so does the total available market for our services and products. Further, our margins associated with services and products for offshore rigs are generally higher than those associated with land rigs.
The continuing high oil and gas prices helped to significantly increase worldwide rig count compared to the same period last year to an average of 2,203 during the quarter. In the second quarter of 2004, the United States rig count increase continued to focus on the land gas drilling as gas prices remained high due to economic demand growth and higher fuel oil prices that discourage switching to a lower-priced fuel source to minimize cost. United States offshore rigs continued to decrease as a result of a weakened Gulf of Mexico region. Year-over-year, international rig count increased primarily in Latin America, Asia
 
  46  

 
Pacific, and the Middle East, offset by declining rig counts in Europe and Africa. In Western Europe, oil company dissatisfaction with high operating costs and inconsistent government policies continued to impede exploration and production recovery.
It is common practice in the United States oilfield services industry to sell services and products based on a price book and then apply discounts to the price book based upon a variety of factors. The discounts applied typically increase to partially or substantially offset price book increases in the weeks immediately following a price increase. The discount applied normally decreases over time if the activity levels remain strong. During periods of reduced activity, discounts normally increase, reducing the net revenue for our services; conversely, during periods of higher activity, discounts normally decline resulting in net revenue increasing for our services. During the second quarter of 2004, general overall discounts were essentially flat. With a tightening of supply and increasing demand for many of our services to the energy industry, we implemented United States price book increases in the second quarter of 2004 of up to 8% in several of our services.
Overall outlook
As we look forward, we see modest growth in the global oilfield services market during 2004. Recently, the Energy Information Administration (EIA) revised upward its forecast of world oil demand annual growth from 2.2% in 2004 and 2005 to 2.8% in 2004 and 2.5% in 2005. The EIA also predicts total demand for petroleum products in the United States in 2004 to increase approximately 1.9%, as increases in transportation- and industrial-related use offset some reductions in heavy fuel oil demand.
According to EIA projections, natural gas demand will increase about 1.1% in 2004 due to increasing economic growth, the lack of fuel-switching options given the high cost of oil, the continuing rise in electricity demand, and below-average hydroelectric power levels in the Pacific Northwest. Demand growth in 2005 is expected to be flat as natural gas end-use prices remain high. Demand growth and limited new supply are expected to keep prices near $6.00 per million cubic feet.
Spears and Associates expects the United States rig count to average 1,169 rigs in 2004, up 7% from its March 2004 estimate. Offshore activity is expected to decline approximately 8% in 2004 compared to 2003. For Canada, Spears is predicting an average of 398 rigs in 2004, which is up from its March 2004 projection. Growth in international drilling activity is expected to remain positive over the coming year. Spears expects the international rig count to rise 6% in 2004 to an average 809 rigs, with 10,083 new wells forecasted to be drilled. Only the European region is expected to see less activity this year. Given the current level of prices, the economic incentive to drill is expected to remain attractive.
Engineering and Construction Group
Our Engineering and Construction Group, operating as KBR, provides a wide range of services to energy and industrial customers and government entities worldwide. Engineering and construction projects are generally longer-term in nature than our Energy Services Group work and are impacted by more diverse drivers than short-term fluctuations in oil and gas prices and drilling activities.
Our government services opportunities continue to remain strong across all regions, with United States government spending in Iraq outpacing other markets. Area security has continued to challenge the reconstruction of Iraq, and the handover from coalition forces to the interim Iraqi government has heightened uncertainty in this post-transition period. If stability is achieved in the coming months, we expect further contracting of the reconstruction plans and much activity in the engineering and construction industry in the Middle East. Due to our presence and performance in Iraq, we believe KBR is well-positioned to be awarded future work in the area. Other more traditional government markets and opportunities ranging from government services, outsourcing, and privatization will continue to mature and may present competitive opportunities.
The drive to monetize gas reserves in the Middle East, West Africa, Asia Pacific, Eurasia, and Latin America, combined with strong demand for gas and liquefied natural gas (LNG) in the United States, Japan, Korea, Taiwan, China, and India, has led to numerous gas to liquid, LNG liquefaction, and gas development projects in the exporting regions, as well as onshore or floating LNG terminals and gas processing plants in the importing countries. Our LNG projects continue to realize good job performance
 
  47  

 
and financial contributions. The combination of tight supply, recovering demand, and new environmental regulations is predicted to drive worldwide refining margins upward in 2004 and lead to an increase in capital spending in all regions.
Outsourcing of operations and maintenance work by industrial and energy companies has been increasing worldwide, and we expect this trend to continue. Our production services arm, which performs engineering modifications and maintenance for upstream hydrocarbons assets, has added substantial new work. Even greater opportunities in this area are anticipated as maturing oilfield assets require improved production efficiency and compliance with tightening emissions regulations. Additionally, concerns about future gas shortages in the United States have resulted in renewed interest in coal bed methane and gas field development, which presents opportunities to provide support services for, or contract operation of, some of these fields.
Engineering and construction contracts can be broadly categorized as either fixed-price, sometimes referred to as lump-sum, or cost-reimbursable contracts. Some contracts can involve both fixed-price and cost-reimbursable elements. Fixed-price contracts are for a fixed sum to cover all costs and any profit element for a defined scope of work. Fixed-price contracts entail more risk to us as we must predetermine both the quantities of work to be performed and the costs associated with executing the work.
Cost-reimbursable contracts include contracts where the price is variable based upon actual costs incurred for time and materials, or for variable quantities of work priced at defined unit rates. Profit elements on cost-reimbursable contracts may be based upon a percentage of costs incurred and/or a fixed amount. Cost-reimbursable contracts are generally less risky, since the owner retains many of the risks. While fixed-price contracts involve greater risk, they also potentially are more profitable for the contractor, since the owners pay a premium to transfer many risks to the contractor.
The approximate percentages of revenue attributable to fixed-price and cost-reimbursable Engineering and Construction Group segment contracts are as follows:

 
 
Fixed-price
Cost-reimbursable

 
 
 
Six months ended June 30, 2004
   
12
%
 
88
%
Year ended December 31, 2003
   
24
%
 
76
%

 
 
 

 
  48  

 
RESULTS OF OPERATIONS IN 2004 COMPARED TO 2003

Second Quarter of 2004 Compared with the Second Quarter of 2003

REVENUES:
 
Second Quarter
Increase/
Percentage
   
   
(Millions of dollars)
 
2004
2003
(Decrease)
Change

 
 
 
 
 
Drilling and Formation Evaluation
 
$
423
 
$
414
 
$
9
   
2
%
Fluids
   
554
   
518
   
36
   
7
 
Production Optimization
   
797
   
692
   
105
   
15
 
Landmark and Other Energy Services
   
130
   
156
   
(26
)
 
(17
)

 
 
 
 
 
Total Energy Services Group
   
1,904
   
1,780
   
124
   
7
 
Engineering and Construction Group
   
3,052
   
1,819
   
1,233
   
68
 

 
 
 
 
 
Total revenues
 
$
4,956
 
$
3,599
 
$
1,357
   
38
%

 
 
 
 
 
 
   
 
   
 
   
 
   
 
 
Geographic – Energy Services Group segments only:
 
 
   
 
 
Drilling and Formation Evaluation:
   
 
   
 
   
 
   
 
 
North America
 
$
140
 
$
127
 
$
13
   
10
%
Latin America
   
71
   
65
   
6
   
9
 
Europe/Africa
   
80
   
91
   
(11
)
 
(12
)
Middle East/Asia
   
132
   
131
   
1
   
1
 

 
 
 
 
 
Subtotal
   
423
   
414
   
9
   
2
 

 
 
 
 
 
Fluids:
   
 
   
 
   
 
   
 
 
North America
   
259
   
251
   
8
   
3
 
Latin America
   
78
   
59
   
19
   
32
 
Europe/Africa
   
127
   
120
   
7
   
6
 
Middle East/Asia
   
90
   
88
   
2
   
2
 
                           

 
 
 
 
 
Subtotal
   
554
   
518
   
36
   
7
 

 
 
 
 
 
Production Optimization:
   
 
   
 
   
 
   
 
 
North America
   
400
   
332
   
68
   
20
 
Latin America
   
85
   
82
   
3
   
4
 
Europe/Africa
   
164
   
146
   
18
   
12
 
Middle East/Asia
   
148
   
132
   
16
   
12
 
                           

 
 
 
 
 
Subtotal
   
797
   
692
   
105
   
15
 

 
 
 
 
 
Landmark and Other Energy Services:
   
 
   
 
   
 
   
 
 
North America
   
47
   
52
   
(5
)
 
(10
)
Latin America
   
23
   
20
   
3
   
15
 
Europe/Africa
   
26
   
37
   
(11
)
 
(30
)
Middle East/Asia
   
34
   
47
   
(13
)
 
(28
)

 
 
 
 
 
Subtotal
   
130
   
156
   
(26
)
 
(17
)

 
 
 
 
 
Total Energy Services Group revenues
 
$
1,904
 
$
1,780
 
$
124
   
7
%

 
 
 
 
 

 
  49  

 

OPERATING INCOME (LOSS):
 
Second Quarter
Increase/
Percentage
   
   
(Millions of dollars)
 
2004
2003
(Decrease)
Change

 
 
 
 
 
Drilling and Formation Evaluation
 
$
59
 
$
49
 
$
10
   
20
%
Fluids
   
77
   
68
   
9
   
13
 
Production Optimization
   
121
   
112
   
9
   
8
 
Landmark and Other Energy Services
   
14
   
6
   
8
   
133
 

 
 
 
 
 
Total Energy Services Group
   
271
   
235
   
36
   
15
 
Engineering and Construction Group
   
(277
)
 
(148
)
 
(129
)
 
(87
)
General corporate
   
(20
)
 
(16
)
 
(4
)
 
(25
)

 
 
 
 
 
Operating income (loss)
 
$
(26
)
$
71
 
$
(97
)
 
(137)
%

 
 
 
 
 

Geographic – Energy Services Group segments only:
 
 
Drilling and Formation Evaluation:
   
 
   
 
   
 
   
 
 
North America
 
$
24
 
$
1
 
$
23
   
NM
 
Latin America
   
9
   
10
   
(1
)
 
(10)
%
Europe/Africa
   
5
   
20
   
(15
)
 
(75
)
Middle East/Asia
   
21
   
18
   
3
   
17
 
                       

 
 
 
 
 
Subtotal
   
59
   
49
   
10
   
20
 

 
 
 
 
 
Fluids:
   
 
   
 
   
 
   
 
 
North America
   
43
   
25
   
18
   
72
 
Latin America
   
13
   
13
   
-
   
-
 
Europe/Africa
   
11
   
18
   
(7
)
 
(39
)
Middle East/Asia
   
10
   
12
   
(2
)
 
(17
)
                           

 
 
 
 
 
Subtotal
   
77
   
68
   
9
   
13
 

 
 
 
 
 
Production Optimization:
   
 
   
 
   
 
   
 
 
North America
   
78
   
60
   
18
   
30
 
Latin America
   
9
   
15
   
(6
)
 
(40
)
Europe/Africa
   
11
   
19
   
(8
)
 
(42
)
Middle East/Asia
   
23
   
18
   
5
   
28
 
                           

 
 
 
 
 
Subtotal
   
121
   
112
   
9
   
8
 

 
 
 
 
 
Landmark and Other Energy Services:
   
 
   
 
   
 
   
 
 
North America
   
7
   
5
   
2
   
40
 
Latin America
   
5
   
5
   
-
   
-
 
Europe/Africa
   
(1
)
 
(6
)
 
5
   
83
 
Middle East/Asia
   
3
   
2
   
1
   
50
 

 
 
 
 
 
Subtotal
   
14
   
6
   
8
   
133
 

 
 
 
 
 
Total Energy Services Group
   
 
   
 
   
 
   
 
 
operating income
 
$
271
 
$
235
 
$
36
   
15
%

 
 
 
 
 
   NM – Not Meaningful

The increase in consolidated revenues for the second quarter of 2004 compared to the second quarter of 2003 was largely attributable to activity in our government services projects, primarily work in the Middle East. International revenue was 71% of consolidated revenues in the second quarter of 2004 and 67% of consolidated revenues in the second quarter of 2003, with the increase attributable to our government services projects abroad. Revenue from the United States Government for all geographic areas was approximately $1.9 billion, or 38% of consolidated revenues, for the second quarter of 2004. Revenue from the United States Government during the same period in 2003 represented 12% of consolidated revenues.
The consolidated operating income decrease in the second quarter of 2004 compared to the second quarter of 2003 was attributable to the charge recorded on our Barracuda-Caratinga project of approximately $310 million in the second quarter of 2004 compared to a $173 million charge recorded in the second quarter of 2003. The charges were partially offset by increases in our government services
 
  50  

 
projects and stronger performance in our Energy Services Group, largely due to favorable changes in oil and gas prices, increased worldwide rig counts, and improved prices in the United States since the second quarter of 2003. During the second quarter of 2004, Iraq-related work contributed approximately $1.7 billion to consolidated revenues and $23 million to consolidated operating income, a 1.4% margin before corporate costs and taxes.
Following is a discussion of our results of operations by reportable segment.
Drilling and Formation Evaluation revenue increased $9 million in the second quarter of 2004 compared to the second quarter of 2003. Sales increases of $12 million for logging and perforating services were primarily due to high land rig count and price increases in the United States and increased sales to China. Drill bits sales contributed approximately $6 million to the increase in revenue due in large part to increased market penetration in roller cone and fixed cutter bits in the United States and an increase in direct sales in Kazakhstan and Turkmenistan. A decrease of $9 million in drilling services revenue was primarily related to the Gulf of Mexico where rig counts declined over 10% compared to the prior year period and to a large direct sale into Russia in the second quarter of 2003. These declines were partially offset by increased onshore a ctivity in the United States and Canada. All geographic regions returned revenue increases for the segment except Europe/Africa. In Europe/Africa, a revenue decline of approximately 12% was primarily due to decline in activity in both the United Kingdom sector of the North Sea and in Africa. International revenue was 72% of total segment revenue in the second quarter of 2004 and in the second quarter of 2003.
Segment increase in operating income was primarily attributable to a $9 million increase in logging and perforating, driven largely by higher United States land rig activity and improved pricing. Drilling services operating income increased $3 million primarily due to a $13 million positive impact of a change in accounting estimate to extend the useful life of directional drilling and logging-while-drilling tools for depreciation purposes, partially offset by weakness in the United Kingdom sector of the North Sea and in Africa. We extended useful lives of these tools based on our review of their service lives, technological improvements in the tools, and recent changes to our repair and maintenance practices which helped to extend the lives. The decrease in drill bits results was due to legal fees related to the Smith International patent infringement litigation (see Note 14 to the co ndensed consolidated financial statements).
Fluids increase in revenue compared to the second quarter of 2003 was driven by a $29 million increase in revenue from cementing activities, which benefited from land rig count increases and price improvements in the United States and new contract awards in Oman. Drilling fluids sales increased $2 million, with increased activity in the United States and new contract awards in Mexico. The increase in revenue in both product lines was partially offset by lower activity in the Gulf of Mexico due to reduction in deepwater activity in the drilling fluids product line combined with poor job mix for cementing services in both shelf and deepwater areas. The Fluids segment saw revenue increases in all geographic regions. International revenue was 57% of total segment revenue in the second quarter of 2004 compared to 55% in the second quarter of 2003.
The Fluids segment operating income increase compared to the second quarter of 2003 resulted from a cementing services increase of $6 million due to higher land rig activity in the United States and improved pricing. Equity losses of $4 million from the Enventure expandable casing joint venture were recorded in the second quarter of 2003 and did not recur in the current year quarter. This joint venture is currently accounted for on the cost basis since reducing our ownership in the first quarter of 2004.
Production Optimization increase in revenue compared to the second quarter of 2003 was mainly attributable to production enhancement services, which increased revenue by $80 million. This was driven by increased rig activity in North America, primarily related to fracturing and acidizing, improved North America pricing, new contract awards in Algeria and Gabon, and continued growth in Russia. Completions and reservoir optimization services contributed $28 million to segment revenue, primarily due to increased tubing-conveyed perforating activity, exploratory testing activity in Europe/Africa and Middle East/Asia, and increased product sales. Segment revenue for the second quarter of 2004 was negatively impacted by
 
  51  

 
$5 million compared to the second quarter of 2003 due to the sale of Halliburton Measurement Systems in May 2003. Production Optimization saw revenue increases in all geographic regions. International revenue was 54% of total segment revenue in the second quarter of 2004 compared to 55% in the second quarter of 2003.
Production Optimization operating income for the second quarter of 2004 increased $9 million as compared to the second quarter of 2003. A gain of $24 million for the sale of Halliburton Measurement Systems was included in the second quarter of 2003. The increase in Production Optimization results was driven by a $27 million increase in production enhancement operating income due to improved equipment and crew utilization and pricing improvements in the United States. Completions and reservoir optimization increase in operating income of $20 million in the second quarter of 2004 compared to the second quarter of 2003 was largely driven by increases in international demand for tubing-conveyed perforating, testing services, completions equipment, and sand control tools. Increases in the segment were partially offset by a decrease of $13 million in equity income from the Subsea 7 joint ve nture, which was adversely impacted by changes in estimated project costs and claims recoveries.
Landmark and Other Energy Services decrease in revenue compared to the second quarter of 2003 was attributable to lower revenue in integrated solutions due to reduced project management work in Iraq, sale of an oil and gas property in Indonesia, and a downward trend in subsea operations. Landmark Graphics second quarter of 2004 revenue increased by 2% compared to second quarter of 2003, due primarily to increased software and hardware sales in Middle East/Asia. International revenue was 67% of total segment revenue in the second quarter of 2004 compared to 72% in the second quarter of 2003.
Segment operating income increased $8 million compared to the second quarter of 2003, despite lower revenues, due to strong commodity prices in integrated solutions services.
Engineering and Construction Group increase in revenue compared to the second quarter of 2003 was due primarily to $1.4 billion increase in government-related activities in the Middle East. In addition, segment revenue increased $84 million from progress on an oil project in Canada and activities at our shipyard in the United Kingdom. Partially offsetting the increases were $202 million lower revenue earned on the Belanak project in Indonesia, the Barracuda-Caratinga project in Brazil, and completion of refining facilities in the United States.
Engineering and Construction Group posted an operating loss of $277 million in the second quarter of 2004 compared to a $148 million loss in the second quarter of 2003. Second quarter of 2004 operating results included a $310 million pretax loss on the Barracuda-Caratinga project compared to a $173 million loss in the second quarter of 2003. The loss in the second quarter of 2004 resulted from a detailed review of the project indicating higher cost estimates, schedule delays, and increased contingencies for the balance of the project. Specifically, in the second quarter, with the integration phase of the Barracuda vessel we experienced a significant reduction in productivity and rework required from the vessel conversion. We have taken steps to mobilize more resources including specialized management personnel in both Houston and South America to oversee the final stages of the projec t. We have conducted additional cost and schedule reviews of the remaining project activities, and we have initiated several work process changes in an attempt to expedite work on the project. In addition, several joint venture infrastructure projects in the Europe/Africa region were negatively affected by projected cost increases. The losses were partially offset by improved results on government-related activities of $12 million and higher contributions of $12 million from an oil project in Canada and production services projects in the United Kingdom.
General corporate expenses were $20 million in the second quarter of 2004 compared to $16 million in the same period of 2003. Included in the second quarter of 2004 expenses is a $7.5 million charge related to our recent settlement with the Securities and Exchange Commission (SEC), which was partially offset by lower expenses due to the sale of an aircraft and a decrease in legal costs. See Note 14 of the condensed consolidated financial statements for more information regarding the SEC settlement.
 
  52  

 
NONOPERATING ITEMS

Interest expense increased $28 million in the second quarter of 2004 compared to the second quarter of 2003, due primarily to interest on $1.2 billion convertible notes issued in June 2003, $1.05 billion senior floating and fixed notes issued in October 2003, and $500 million senior floating rate notes issued in January 2004.
Foreign currency losses, net for the second quarter of 2004 were $7 million compared to a gain of $19 million for the same period of 2003. The current quarter loss is primarily related to losses in Indonesia and devaluation of the Eurodollar. The gain in the second quarter of 2003 was primarily due to gains in the United Kingdom and Canada.
Benefit for income taxes of $29 million resulted in an effective tax rate of 36% in the second quarter of 2004, compared to an effective tax rate of 39% in the second quarter of 2003. The tax rate on the loss for the second quarter of 2004 was attributable to lower tax benefits on the Barracuda-Caratinga charge, partially offset by a reduction of current taxes in foreign jurisdictions.
Loss from discontinued operations, net of tax in the second quarter of 2004 includes a $680 million pretax charge related to the write-down of our insurance receivable associated with our asbestos- and silica-related liabilities and an $11 million write-off of fees related to the delayed-draw term facility which expired on June 30, 2004. Discontinued operations loss in the second quarter of 2003 reflects a $30 million pretax charge related to the July 2003 funding of the debtor-in-possession financing to Harbison-Walker in connection with their Chapter 11 bankruptcy proceeding.
 
  53  

 
RESULTS OF OPERATIONS IN 2004 COMPARED TO 2003

First Six Months of 2004 Compared with the First Six Months of 2003

REVENUES:
 
First Six Months
Increase/
Percentage
   
   
(Millions of dollars)
 
2004
2003
(Decrease)
Change

 



Drilling and Formation Evaluation
 
$
867
 
$
793
 
$
74
   
9
%
Fluids
   
1,089
   
998
   
91
   
9
 
Production Optimization
   
1,505
   
1,319
   
186
   
14
 
Landmark and Other Energy Services
   
259
   
281
   
(22
)
 
(8
)

 
 
 
 
 
Total Energy Services Group
   
3,720
   
3,391
   
329
   
10
 
Engineering and Construction Group
   
6,755
   
3,268
   
3,487
   
107
 

 
 
 
 
 
Total revenues
 
$
10,475
 
$
6,659
 
$
3,816
   
57
%

 
 
 
 
 
 
   
 
   
 
   
 
   
 
 
Geographic – Energy Services Group segments only:
 
 
   
 
 
Drilling and Formation Evaluation:
   
 
   
 
   
 
   
 
 
North America
 
$
293
 
$
265
 
$
28
   
11
%
Latin America
   
136
   
121
   
15
   
12
 
Europe/Africa
   
161
   
163
   
(2
)
 
(1
)
Middle East/Asia
   
277
   
244
   
33
   
14
 

 
 
 
 
 
Subtotal
   
867
   
793
   
74
   
9
 

 
 
 
 
 
Fluids:
   
 
   
 
   
 
   
 
 
North America
   
518
   
498
   
20
   
4
 
Latin America
   
152
   
112
   
40
   
36
 
Europe/Africa
   
245
   
225
   
20
   
9
 
Middle East/Asia
   
174
   
163
   
11
   
7
 
                           

 
 
 
 
 
Subtotal
   
1,089
   
998
   
91
   
9
 

 
 
 
 
 
Production Optimization:
   
 
   
 
   
 
   
 
 
North America
   
754
   
648
   
106
   
16
 
Latin America
   
158
   
146
   
12
   
8
 
Europe/Africa
   
310
   
270
   
40
   
15
 
Middle East/Asia
   
283
   
255
   
28
   
11
 
                           

 
 
 
 
 
Subtotal
   
1,505
   
1,319
   
186
   
14
 

 
 
 
 
 
Landmark and Other Energy Services:
   
 
   
 
   
 
   
 
 
North America
   
95
   
96
   
(1
)
 
(1
)
Latin America
   
40
   
29
   
11
   
38
 
Europe/Africa
   
53
   
78
   
(25
)
 
(32
)
Middle East/Asia
   
71
   
78
   
(7
)
 
(9
)

 
 
 
 
 
Subtotal
   
259
   
281
   
(22
)
 
(8
)

 
 
 
 
 
Total Energy Services Group revenues
 
$
3,720
 
$
3,391
 
$
329
   
10
%

 
 
 
 
 
 
  54  

 

OPERATING INCOME (LOSS):
 
First Six Months
Increase/
Percentage
   
   
(Millions of dollars)
 
2004
2003
(Decrease)
Change

 
 
 
 
 
Drilling and Formation Evaluation
 
$
102
 
$
115
 
$
(13
)
 
(11)
%
Fluids
   
137
   
123
   
14
   
11
 
Production Optimization
   
203
   
180
   
23
   
13
 
Landmark and Other Energy Services
   
43
   
(3
)
 
46
   
NM
 

 
 
 
 
 
Total Energy Services Group
   
485
   
415
   
70
   
17
 
Engineering and Construction Group
   
(292
)
 
(167
)
 
(125
)
 
(75
)
General corporate
   
(44
)
 
(35
)
 
(9
)
 
(26
)

 
 
 
 
 
Operating income
 
$
149
 
$
213
 
$
(64
)
 
(30)
%

 
 
 
 
 

Geographic – Energy Services Group segments only:
 
 
Drilling and Formation Evaluation:
   
 
   
 
   
 
   
 
 
North America
 
$
41
 
$
40
 
$
1
   
3
%
Latin America
   
14
   
15
   
(1
)
 
(7
)
Europe/Africa
   
9
   
31
   
(22
)
 
(71
)
Middle East/Asia
   
38
   
29
   
9
   
31
 
                           

 
 
 
 
 
Subtotal
   
102
   
115
   
(13
)
 
(11
)

 
 
 
 
 
Fluids:
   
 
   
 
   
 
   
 
 
North America
   
74
   
49
   
25
   
51
 
Latin America
   
24
   
25
   
(1
)
 
(4
)
Europe/Africa
   
22
   
30
   
(8
)
 
(27
)
Middle East/Asia
   
17
   
19
   
(2
)
 
(11
)
                           

 
 
 
 
 
Subtotal
   
137
   
123
   
14
   
11
 

 
 
 
 
 
Production Optimization:
   
 
   
 
   
 
   
 
 
North America
   
125
   
95
   
30
   
32
 
Latin America
   
19
   
30
   
(11
)
 
(37
)
Europe/Africa
   
15
   
22
   
(7
)
 
(32
)
Middle East/Asia
   
44
   
33
   
11
   
33
 
                           

 
 
 
 
 
Subtotal
   
203
   
180
   
23
   
13
 

 
 
 
 
 
Landmark and Other Energy Services:
   
 
   
 
   
 
   
 
 
North America
   
30
   
(9
)
 
39
   
NM
 
Latin America
   
9
   
(4
)
 
13
   
NM
 
Europe/Africa
   
(1
)
 
-
   
(1
)
 
NM
 
Middle East/Asia
   
5
   
10
   
(5
)
 
(50
)

 
 
 
 
 
Subtotal
   
43
   
(3
)
 
46
   
NM
 

 
 
 
 
 
Total Energy Services Group
   
 
   
 
   
 
   
 
 
operating income
 
$
485
 
$
415
 
$
70
   
17
%

 
 
 
 
 
   NM – Not Meaningful

The increase in consolidated revenues for the first six months of 2004 compared to the first six months of 2003 was largely attributable to activity in our government services projects, primarily work in the Middle East. International revenue was 74% of consolidated revenues in the first six months of 2004 and 67% of consolidated revenues in the first six months of 2003, with the increase attributable to our government services projects abroad. Revenue from the United States Government for all geographic areas was approximately $4.5 billion, or 43% of consolidated revenues, for the first six months of 2004. Revenue from the United States Government during the same period in 2003 represented approximately 10% of consolidated revenues.
The consolidated operating income decrease was primarily due to $407 million of charges related to our Barracuda-Caratinga project in the first six months of 2004 compared to $228 million in the first six months of 2003, partially offset by increases in our government services projects and stronger performance
 
  55  

 
in our Drilling and Formation Evaluation, Fluids, and Production Optimization segments, largely due to favorable changes in oil prices and rig counts in the first six months of 2004. During the first six months of 2004, Iraq-related work contributed approximately $4 billion to consolidated revenues and $60 million to consolidated operating income, a 1.5% margin before corporate costs and taxes.
Following is a discussion of our results of operations by reportable segment.
Drilling and Formation Evaluation revenue increase in the first half of 2004 was largely driven by a $52 million increase in logging and perforating services due to higher land rig count and price increases in the United States and a large direct sale into China. Drill bits revenue increased $15 million, benefiting from increases in land rig counts, improved pricing, and increased market penetration in roller cone and fixed cutter bits in the United States and Canada. Drilling services contributed $5 million to the increase due to growth in Norway as a result of previously announced new contract awards and increased activity in Brazil in the first six months of 2004, which were partially offset by a significant decline in activity in the Gulf of Mexico. International revenue was 73% of total segment revenues in the first six months of 2004 compared to 72% in the first six months of 2003.
The decrease in operating income for the segment in the first six months of 2004 reflects a $36 million pretax gain on the disposition of Mono Pumps in the first quarter of 2003. Offsetting this was improved contribution by logging and perforating services of $23 million, driven largely by price increases in the United States and significant cost reductions in Nigeria and Angola. Drilling services operating income reflects an increase of $13 million due to a change in accounting estimate to extend the useful life of directional drilling and logging-while-drilling tools for depreciation purposes, partially offset by weakness in the United Kingdom sector of the North Sea and in Africa. We extended useful lives of these tools based on our review of their service lives, technological improvements in the tools, and recent changes to our repair and maintenance practices which helped to exte nd the lives.
Fluids revenue increase compared to the first six months of 2003 was driven by a $75 million improvement in revenue from cementing activities, due to increased land rig count and price improvements in the United States and new contract awards in Mexico, Norway, and Oman. Drilling fluids contributed $6 million to segment revenue due to increases in the United States and Canada, primarily based on increases in natural gas prices, and the award of new contracts in Norway, Mexico, and Venezuela. Drilling fluids revenue was significantly impacted by reduced activity in the Gulf of Mexico and Nigeria. International revenue was 58% of total segment revenues in the first six months of 2004 compared to 55% in the first six months of 2003.
The Fluids segment operating income increase compared to the first half of 2003 resulted from a cementing services increase of $21 million, partially offset by lower results from drilling fluids of $13 million. The increase in cementing results occurred predominantly in North America due to increased land rig activity in the United States and Canada and pricing improvements. Drilling fluids results were negatively impacted by reduced activity in the Gulf of Mexico and Nigeria. Also included in the Fluids segment operating income comparison was a $6 million increase due to a loss recorded in our Enventure expandable casing joint venture in the first six months of 2003, which did not recur in the first six months of 2004. We have been accounting for Enventure on the cost method since reducing our ownership interest in the first quarter of 2004.
Production Optimization increase in revenue compared to the first six months of 2003 was mainly attributable to production enhancement services, which increased revenue by $156 million. This was driven by increased activity in North America primarily related to fracturing and acidizing, new hydraulic workover services, new contract awards in Algeria and Gabon, and continued growth in Russia. Completions and reservoir optimization services contributed $36 million to segment revenue, primarily due to increased tubing-conveyed perforating activity and exploratory testing activity in the United Kingdom, Algeria, Indonesia, and Norway, and increased product sales. The completions and reservoir optimization revenue comparison was negatively impacted by $14 million due to the sale of Halliburton Measurement Systems in May 2003 and a significant reduction in deepwater activity in the Gulf of Mexico. Production Optimization saw revenue increases in all geographic regions. International revenue was 55% of total segment revenue in the first six months of 2004 compared to 54% in the first six months of 2003.
 
  56  

 
Production Optimization operating income for the first half of 2004 increased $23 million as compared to the first half of 2003. A gain of $24 million from the sale of Halliburton Measurement Systems was included in the second quarter of 2003. The improvement in Production Optimization results was driven by a $49 million increase in production enhancement due to improved equipment and crew utilization and increased land rig count and pricing improvements in the United States. Strong results in the United States were partially offset by declines in the international markets due to lower vessel utilization in the North Sea and offshore Angola, Brazil, and Mexico. Completions and reservoir optimization increase of $15 million in the first six months of 2004 compared to the first six months of 2003 was largely driven by increases in international demand for tubing-conveyed perforating and testing services resulting in improvements in equipment and crew utilization. Additionally, increased sales of completions and sand control tools in the United Kingdom and increased sales in Norway contributed to higher operating income in the first half of 2004. Increases in segment results were partially offset by a decrease of $16 million in equity income from our Subsea 7 joint venture, which was adversely impacted by changes in estimated project costs and claims recoveries.
Landmark and Other Energy Services revenue decrease in the first half of 2004 was due to lost revenues of $11 million from the sale of Wellstream in the first quarter of 2003, a decrease in integrated solutions services due to reduced project management work in Iraq, the sale of an oil and gas property in Indonesia, and a downward trend in subsea operations. These decreases were partially offset by increased revenue of 3% from Landmark Graphics, due to higher software, hardware, and consulting sales in Middle East/Asia and Latin America. International revenue was 67% of total segment revenue in the first six months of 2004 compared to 70% in the first six months of 2003.
Segment operating income increased $46 million from a loss position in the first six months of 2003. Contributing to this increase was a $15 million pretax loss on the disposition of Wellstream in the first quarter of 2003, a $13 million release of legal liability accruals in the first quarter of 2004 pertaining to the April 2004 settlement in the Anglo-Dutch (Tenge) litigation, and increased operating income in integrated solutions services due to strong commodity prices.
Engineering and Construction Group increase in revenue compared to the first six months of 2003 was due primarily to $3.6 billion in government-related activities in the Middle East, and, to a lesser extent, a $269 million increase in other government projects and an oil project in Canada. Partially offsetting the revenue increases were lower revenues of $415 million earned on the Barracuda-Caratinga project in Brazil, the Belanak project in Indonesia, completion of refining facilities in the United States, and gas projects in Nigeria.
Engineering and Construction group operating loss for the first six months of 2004 was $292 million compared to a $167 million loss in the first six months of 2003. Included in the 2004 results was a loss on the Barracuda-Caratinga project of $407 million compared to a $228 million loss in 2003. In addition, several joint venture infrastructure projects in the Europe/Africa region were negatively affected by projected cost increases. The losses were partially offset by improved results on government-related activities of $58 million and, to a lesser extent, higher contributions of $22 million from an oil project in Canada, and production services projects in the United Kingdom.
General corporate expenses for the first six months of 2004 were $44 million compared to $35 million for the first six months of 2003. General corporate expenses for the first six months of 2004 included a $7.5 million charge related to our recent settlement with the SEC. See Note 14 of the condensed consolidated financial statements for more information.

NONOPERATING ITEMS

Interest expense increased $57 million in the first six months of 2004 compared to the first six months of 2003, due primarily to interest on $1.2 billion convertible notes issued in June 2003, $1.05 billion senior floating and fixed notes issued in October 2003, and $500 million senior floating rate notes issued in January 2004.
 
  57  

 
Foreign currency losses, net for the first six months of 2004 were $10 million compared to a gain of $13 million for the same period of 2003. The losses in 2004 were primarily due to losses in Indonesia and devaluation of the Eurodollar. The gain in 2003 was due to gains in the United Kingdom and Canada.
Other, net in the first six months of 2004 primarily reflects a $6 million pretax gain on the sale of our remaining shares of National Oilwell, Inc. common stock received in the January 2003 disposition of Mono Pumps.
Provision for income taxes of $20 million resulted in an effective tax rate of 39% in the first six months of 2004, compared to an effective tax rate of 41% in the first six months of 2003. The high tax rate for the first six months of 2004 was attributable to lower tax benefits on the Barracuda-Caratinga charge, partially offset by a reduction of current taxes in foreign jurisdictions. The higher tax rate for the first six months of 2003 was mostly the result of the tax effect on the gain from the sale of our Mono Pumps business and loss from the sale of Wellstream. These transactions included $14 million of realized cumulative translation loss, which is not deductible for tax purposes.
Loss from discontinued operations, net of tax in the first six months of 2004 includes a $680 million pretax charge related to the write-down of the asbestos and silica insurance receivable, a $190 million pretax charge for the revaluation of the 59.5 million shares of Halliburton common stock to be contributed to the asbestos and silica claimant trusts as part of the proposed settlement recorded in the first quarter of 2004, and an $11 million pretax charge related to the delayed-draw term facility, which expired in June 2004. The remaining $15 million consists of professional and administrative fees related to various aspects of the proposed asbestos and silica settlement. The loss from discontinued operations was $24 million in the first six months of 2003.
Cumulative effect of change in accounting principle, net for the first six months of 2003 was an $8 million after-tax charge, or $0.02 per diluted share, related to our January 1, 2003 adoption of Financial Accounting Standards Board Statement No. 143, “Accounting for Asset Retirement Obligations.”

OFF BALANCE SHEET RISK

In April 2004, the expiration date for our Energy Services Group accounts receivable securitization facility was extended to April 2005. We have the ability to sell up to $300 million under the facility. As of June 30, 2004, we had sold $268 million undivided ownership interest to unaffiliated companies.
In May 2004, KBR entered into an agreement to sell, assign, and transfer its entire title and interest in specified accounts receivable to a third party. The face value of the receivables sold to the third party is reflected as a reduction of accounts receivable in our condensed consolidated balance sheets. The amount of receivables which can be sold under the agreement varies based on the amount of eligible KBR receivables at any given time and other factors, and the maximum amount that may be sold and outstanding under this agreement at any given time is $650 million. The total amount of receivables sold under this agreement as of June 30, 2004 was approximately $50 million.

ENVIRONMENTAL MATTERS

We are subject to numerous environmental, legal, and regulatory requirements related to our operations worldwide. In the United States, these laws and regulations include, among others:
-   the Comprehensive Environmental Response, Compensation, and Liability Act;
-   the Resources Conservation and Recovery Act;
-   the Clean Air Act;
-   the Federal Water Pollution Control Act; and
-   the Toxic Substances Control Act.
In addition to the federal laws and regulations, states and other countries where we do business may have numerous environmental, legal, and regulatory requirements by which we must abide. We evaluate and address the environmental impact of our operations by assessing and remediating
 
  58  

 
contaminated properties in order to avoid future liabilities and comply with environmental, legal, and regulatory requirements. On occasion, we are involved in specific environmental litigation and claims, including the remediation of properties we own or have operated, as well as efforts to meet or correct compliance-related matters. Our Health, Safety and Environment group has several programs in place to maintain environmental leadership and to prevent the occurrence of environmental contamination.
We do not expect costs related to these remediation requirements to have a material adverse effect on our consolidated financial position or our results of operations. Our accrued liabilities for environmental matters were $38 million as of June 30, 2004 and $31 million as of December 31, 2003. The liability covers numerous properties and no individual property accounts for more than $5 million of the liability balance. In some instances, we have been named a potentially responsible party by a regulatory agency, but in each of those cases, we do not believe we have any material liability. We have subsidiaries that have been named as potentially responsible parties along with other third parties for 13 federal and state superfund sites for which we have established a liability. As of June 30, 2004, those 13 sites accounted for approximately $9 million of our total $38 million liability .

FORWARD-LOOKING INFORMATION AND RISK FACTORS

The Private Securities Litigation Reform Act of 1995 provides safe harbor provisions for forward-looking information. Forward-looking information is based on projections and estimates, not historical information. Some statements in this Form 10-Q are forward-looking and use words like “may,” “may not,” “believes,” “do not believe,” “expects,” “do not expect,” “anticipates,” “do not anticipate,” and other expressions. We may also provide oral or written forward-looking information in other materials we release to the public. Forward-looking information involves risks and uncertainties and reflects our best judgment based on current information. Our results of operations can be affected by inaccurate assumptions we make or by known or unknown risks and uncertainties. In addition, other factors may affect the accuracy of our forward-looking information. As a result, no forward-looking information can be guaranteed. Actual events and the results of operations may vary materially.
We do not assume any responsibility to publicly update any of our forward-looking statements regardless of whether factors change as a result of new information, future events, or for any other reason. You should review any additional disclosures we make in our press releases and Forms 10-K, 10-Q, and 8-K filed with the United States Securities and Exchange Commission. We also suggest that you listen to our quarterly earnings release conference calls with financial analysts.
While it is not possible to identify all factors, we continue to face many risks and uncertainties that could cause actual results to differ from our forward-looking statements and potentially materially and adversely affect our financial condition and results of operations, including risks relating to:

Asbestos and Silica Liability
Our ability to complete our proposed settlement and plan of reorganization
On July 21, 2004, the bankruptcy court entered an order, effective as of July 16, 2004, confirming the proposed plan of reorganization to implement our proposed asbestos and silica settlement. On July 26, 2004, certain of our insurance companies filed a notice of appeal concerning the bankruptcy court’s confirmation. Also on July 26, 2004, the United States District Court for the Western District of Pennsylvania affirmed the confirmation order. If our previously announced agreements in principle with our insurance companies are finalized and approved by the relevant bankruptcy courts, we believe that the insurance companies will dismiss their notice of appeal, that the District Court’s affirmation order will become final and nonappealable and that the plan of reorganization will become effective. However, there can be no assurance that we will obtain all of the required judi cial approval of the proposed plan of reorganization or any amended plan of reorganization that we may propose if a final order affirming the proposed plan of reorganization is not issued.
 
  59  

 
Completion of the proposed plan of reorganization is also conditioned on continued availability of financing on terms acceptable to us in order to allow us to fund the cash amounts to be paid in the plan of reorganization. There can be no assurance that such conditions will be met.
Effect of inability to complete a plan of reorganization
If the currently proposed plan of reorganization does not become effective and the Chapter 11 proceedings are not dismissed, the Debtors could propose a new plan of reorganization. Chapter 11 permits a company to remain in control of its business, protected by a stay of all creditor action, while that company attempts to negotiate and confirm a plan of reorganization with its creditors. However, it is uncertain for how long a period of time the bankruptcy court would permit the debtors to retain their exclusive right to file an amended plan of reorganization. If the Debtors are unsuccessful in obtaining confirmation of the currently proposed plan of reorganization or an amended plan of reorganization, the assets of the Debtors could be liquidated in the Chapter 11 proceedings, a third party may obtain the right to file a plan of reorganization, the Chapter 11 proceedings could be conv erted to proceedings under Chapter 7 of the United States Bankruptcy Code or the cases could be dismissed. In the event of a liquidation of the Debtors, or a plan of reorganization proposed by a third party, Halliburton could lose its controlling interest in DII Industries and Kellogg Brown & Root. Moreover, if the plan of reorganization is not confirmed and the Debtors have insufficient assets to pay the creditors, Halliburton’s assets could be drawn into the liquidation proceedings because Halliburton guarantees certain of the Debtors’ obligations.
Proposed federal legislation may affect our liability and agreements
We understand that the United States Congress may consider adopting legislation that would set up a national trust fund as the exclusive means for recovery for asbestos-related disease. We are uncertain as to what contributions we would be required to make to a national trust, if any, although it is possible that they could be substantial and that they could continue for several years. Our level of participation in and contribution to a national trust could be greater or less than it otherwise would have been as a result of having subsidiaries that have filed Chapter 11 proceedings due to asbestos liabilities.
Under the terms of our announced insurance settlements and proposed insurance settlements, we expect to receive cash proceeds with a present value of approximately $1.4 billion for our asbestos- and silica-related insurance receivables. However, one of the conditions to the effectiveness of our announced and proposed insurance settlements is or, with respect to the proposed settlements, is expected to be, that no law shall be passed by the United States Congress that relates to, regulates, limits, or controls the prosecution of asbestos claims in United States state or federal courts or any other forum. If national asbestos litigation legislation in the form presently being considered is passed by the United States Congress on or before January 5, 2005 and becomes law, and our plan of reorganization has become final and nonappealable before passage of the new legislation, we would not receive the $1.4 billion in cash provided by these settlements, but we would retain the rights we currently have against our insurance companies, which includes coverage with a face amount of more than $3 billion.
Possible remaining asbestos and silica exposure
An effective plan of reorganization and injunctions under Sections 524(g) and 105 of the United States Bankruptcy Code may not apply to protect against all asbestos and silica claims asserted against us in jurisdictions outside the United States. For example, while we have historically not received a significant number of claims outside the United States, any such future claims would be subject to the applicable legal system of the jurisdiction where the claim was made. The enforceability of injunctions under the United States Bankruptcy Code in such jurisdictions is uncertain. In addition, the Section 524(g) injunction would not apply to some claims under worker’s compensation arrangements. Although we do not believe that we have material exposure to foreign or worker’s compensation claims, there can be no assurance that material claims would not be made in the future. Furt her, to our knowledge, the constitutionality of an injunction under Section 524(g) of the United States Bankruptcy Code has not been tested in a court of law. We can provide no assurance that, if the constitutionality is challenged, the injunction would be upheld.
 
  60  

 
In addition, although we would have other significant affirmative defenses, the injunctions issued under the United States Bankruptcy Code may not cover all silica personal injury claims arising as a result of future silica exposure after the effective date of the proposed plan of reorganization. Moreover, the proposed plan of reorganization does not resolve claims for property damage as a result of materials containing asbestos. Accordingly, although we have historically received no such claims, claims could still be made as to damage to property or property value as a result of asbestos-containing products having been used in a particular property or structure.
Insurance recoveries
In January 2004, we reached a comprehensive agreement with Equitas to settle our insurance claims against certain underwriters at Lloyd’s of London, reinsured by Equitas, for asbestos- and silica-related claims and all other claims under the applicable insurance policies. There are conditions to completion of the settlement with Equitas, and there can be no assurance that this settlement will be completed on the terms announced. We are also negotiating settlement agreements with other insurance companies.
In May 2004, we entered into nonbinding agreements in principle with representatives of the London Market insurance companies that, if implemented, would settle insurance disputes with substantially all the solvent London Market insurance companies for asbestos- and silica-related claims and all other claims under the applicable insurance policies. The agreements in principle with the London Market insurance companies are subject to board of directors’ approval of all parties, agreement by all remaining London Market insurance companies, and an order by the bankruptcy court confirming our proposed plan of reorganization that has become final and nonappealable.
We also expect to shortly enter into a nonbinding agreement in principle with our solvent domestic insurance companies that, if implemented, would settle asbestos- and silica-related claims and all other claims under the applicable insurance policies and terminate all the applicable insurance policies. The final settlement agreement with the domestic insurance companies would be subject to board of directors’ approval of all parties, an order by the bankruptcy court approving the final settlement agreement, agreement by Federal-Mogul and Cooper concerning DII Industries’ rights to access certain of the insurance policies, approval by the Federal-Mogul bankruptcy court of the agreement with Federal-Mogul and Cooper, and an order by the bankruptcy court confirming our proposed plan of reorganization that has become final and nonappealable.
These proposed settlements with our insurance companies are subject to numerous conditions, including the conditions of the Equitas settlement, which include the condition that the United States Congress does not pass national asbestos litigation reform legislation before January 5, 2005.
Under the terms of our announced insurance settlements and proposed insurance settlements, we expect to receive cash proceeds with a nominal amount of $1.5 billion and a present value of approximately $1.4 billion for our asbestos- and silica-related insurance receivables. The present value was determined by discounting the expected future cash payments with a discount rate implicit in the settlements which is approximately 5.5% related to the domestic insurance companies. This discount will be accreted as interest income (classified as discontinued operations) over the life of the expected future cash payments beginning in the third quarter of 2004.
Our December 31, 2003 estimate of our asbestos- and silica-related insurance receivables already included the charge for the settlement amount under the Equitas agreement reached in January 2004, as well as certain other probable settlements with companies for which we could reasonably estimate the amount of the settlement. In the second quarter of 2004, we reduced the amount recorded as insurance receivables for asbestos- and silica-related liabilities insured by domestic companies, based upon the proposed agreement in principle, resulting in a pretax charge to discontinued operations of approximately $680 million.
Although we are working toward implementation of these announced and proposed insurance settlements, there can be no assurance that such settlements can be completed on the terms as either announced or proposed. In addition, if we are unable to complete our announced and proposed insurance
 
  61  

 
settlements, we may be unable to recover, or we may be delayed in recovering, insurance reimbursements related to asbestos and silica claims due to, among other things:
-   the inability or unwillingness of insurance companies to timely reimburse for claims in the future;
-   disputes as to documentation requirements for DII Industries, Kellogg Brown & Root, or other subsidiaries in order to recover claims paid;
-   the inability to access insurance policies shared with, or the dissipation of shared insurance assets by, Harbison-Walker Refractories Company, Federal-Mogul, or others;
-   the possible insolvency or reduced financial viability of our insurance companies;
-   the cost of litigation to obtain insurance reimbursement; and
-   possible adverse court decisions as to our rights to obtain insurance reimbursement.
Effect of Chapter 11 proceedings on our business and operations
Because our financial condition and our results of operations depend on distributions from our subsidiaries, any prolonged Chapter 11 proceedings of those subsidiaries, including DII Industries and Kellogg Brown & Root, may have a negative impact on our cash flow and distributions from those subsidiaries. These subsidiaries are not able to make distributions of profits to Halliburton during the Chapter 11 proceedings without court approval. In addition, the Chapter 11 proceedings could materially and adversely affect the ability of our subsidiaries in Chapter 11 proceedings to obtain new orders from current or prospective customers. As a result of any prolonged Chapter 11 proceedings, some current and prospective customers, suppliers, and other vendors may assume that our subsidiaries are financially weak and will be unable to honor obligations, making those customers, suppliers, and other vendors reluctant to do business with our subsidiaries. In particular, some governments may be unwilling to conduct business with a subsidiary in a Chapter 11 proceeding. Consequently, our financial condition and results of operations could be materially and adversely affected.
Further, prolonged Chapter 11 proceedings could materially and adversely affect the relationship that DII Industries, Kellogg Brown & Root, and their subsidiaries involved in the Chapter 11 proceedings have with their customers, suppliers, and employees, which in turn could materially and adversely affect their competitive positions, financial conditions, and results of operations. A weakening of their financial conditions and results of operations could materially and adversely affect their ability to implement the plan of reorganization.

Legal Matters
Audits and inquiries about government contracts work
We provide substantial work under our government contracts business to the United States Department of Defense and other governmental agencies, including worldwide United States Army logistics contracts, known as LogCAP, and contracts to rebuild Iraq’s petroleum industry, known as RIO I and PCO Oil South (formerly RIO II). Our government services revenue related to Iraq totaled approximately $1.7 billion and $4 billion for the three and six months ended June 30, 2004. Our units operating in Iraq and elsewhere under government contracts such as LogCAP, RIO I, and PCO Oil South consistently review the amounts charged and the services performed under these contracts. Our operations under these contracts are also regularly reviewed and audited by the Defense Contract Audit Agency (DCAA) and other governmental agencies. When issues are found during the governmental agency audit proces s, these issues are typically discussed and reviewed with us in order to reach a resolution.
The results of a preliminary audit by the DCAA in December 2003 alleged that we may have overcharged the Department of Defense by $61 million in importing fuel into Iraq. After a review, the Army Corps of Engineers, which is our client and oversees the project, concluded that we obtained a fair price for the fuel. However, Department of Defense officials thereafter referred the matter to the agency’s inspector general, which we understand has commenced an investigation.
We have had inquiries in the past by the DCAA and the civil fraud division of the United States Department of Justice into possible overcharges for work performed during 1996 through 2000 under a contract in the Balkans, which inquiry has not yet been completed by the Department of Justice. Based on
 
  62  

 
an internal investigation, we credited our customer approximately $2 million during 2000 and 2001 related to our work in the Balkans as a result of billings for which support was not readily available. We believe that the preliminary Department of Justice inquiry relates to potential overcharges in connection with a part of the Balkans contract under which approximately $100 million in work was done. The Department of Justice has not alleged any overcharges, and we believe that any allegation of overcharges would be without merit.
On January 22, 2004, we announced the identification by our internal audit function of a potential overbilling of approximately $6 million by one of our subcontractors under the LogCAP contract in Iraq for services performed during 2003. In accordance with our policy and government regulation, the potential overcharge was reported to the Department of Defense Inspector General’s office as well as to our customer, the Army Materiel Command. On January 23, 2004, we issued a check in the amount of $6 million to the Army Materiel Command to cover that potential overbilling while we conducted our own investigation into the matter. Later in the first quarter of 2004, we determined that the amount of overbilling was $4 million and the subcontractor billing should have been $2 million for the services provided. As a result, we have processed payment for $2 million and have billed our cus tomer that amount. We are continuing to investigate whether third-party subcontractors paid, or attempted to pay, one or two of our former employees in connection with the billing.
We understand that the United States Department of Justice and an Assistant United States Attorney based in Illinois are investigating some of these matters. We also understand that former employees of KBR have received subpoenas and have given or may give grand jury testimony relating to some of these matters. If criminal wrongdoing were found, criminal penalties could range up to the greater of $500,000 in fines per count for a corporation, or twice the gross pecuniary gain or loss.
During 2003, the DCAA raised issues relating to our invoicing to the Army Materiel Command for food services for soldiers and supporting civilian personnel in Iraq and Kuwait. We believe the issues raised by the DCAA relate to the difference between the number of troops the Army Materiel Command directed KBR to support and the number of soldiers actually served at dining facilities for United States troops and supporting civilian personnel in Iraq and Kuwait. In the first quarter of 2004, we reviewed our DFACs in our Iraq and Kuwait areas of operation and have billed and continue to bill for all current DFAC costs. During the second quarter of 2004, we received notice from the DCAA that it is recommending withholding a portion of all our DFAC billings. The amount withheld totaled approximately $203 million as of June 30, 2004. The DCAA is continuing to recommend withholding 19.35% of payments on future DFAC billings relating to subcontracts entered into prior to February 2004. We are negotiating with our customer, the Army Materiel Command, and the DCAA in an attempt to settle these issues.
During 2004, the Army Materiel Command issued mandates that could cause it to withhold 15% from our invoices to be paid after August 15, 2004 until our task orders under the LogCAP contract are definitized. We do not believe the potential 15% withholding will have a significant or sustained impact on our liquidity because the withholding is temporary and ends once the definitization process is complete.
During the second quarter of 2004, the Army Corps of Engineers withheld $57 million of our invoices related to a portion of our RIO I contract pending completion of the definitization process. All ten definitization proposals required under this contract have been submitted and two have been negotiated. The remaining eight are in DCAA audit. These withholdings represent the amount invoiced in excess of 85% of the currently estimated amounts. The Army Corps of Engineers also could withhold similar amounts from future invoices under our RIO I contract until our task orders under the RIO I contract are definitized. We do not believe the withholding will have a significant or sustained impact on our liquidity because the withholding is temporary and ends once the definitization process is complete.
All of these matters are still under review by the applicable government agencies. Additional review is likely, and the dollar amounts at issue could change significantly. We could also be subject to future DCAA inquiries for other services we provide in Iraq under the current LogCAP contract, RIO I contract, or the PCO Oil South contract. For example, as a result of an increase in the level of work performed in Iraq or the DCAA’s review of additional aspects of our services performed in Iraq, it is
 
  63  

 
possible that we may, or may be required to, withhold additional invoicing or make refunds to our customer, some of which could be substantial, until these matters are resolved. This could materially and adversely affect our liquidity.
Typically, when issues are found during the governmental agency audit process, they are discussed and reviewed by the governmental agency with the contractor in order to reach a resolution. However, to the extent we or our subcontractors make mistakes in our government contract operations, even if unintentional, insignificant, or subsequently self-reported to the applicable government agency, we have been and will likely continue to be subject to more intense scrutiny. Some of this scrutiny is a result of the Vice President of the United States being a former chief executive officer of Halliburton. This scrutiny has recently centered on our government contracts work, especially in Iraq and other parts of the Middle East. In part because of the heightened level of scrutiny under which we operate, audit issues between us and government auditors like the DCAA or the inspector general of the Department of Defense may arise and are more likely to become public. We could be asked to reimburse payments made to us that are determined to be in excess of those allowed by the applicable contract, or we could agree to delay billing for an indefinite period of time for work we have performed until any billing and cost issues are resolved. Our ability to secure future government contracts business or renewals of current government contracts business in the Middle East or elsewhere could be materially and adversely affected. In addition, we may be required to expend a significant amount of resources explaining and/or defending actions we have taken under our government contracts.
Nigerian joint venture
The SEC has commenced a formal investigation into payments made in connection with the construction and subsequent expansion by TSKJ of a multibillion dollar natural gas liquefaction complex and related facilities at Bonny Island in Rivers State, Nigeria. The United States Department of Justice is also investigating. The SEC and the Department of Justice have been reviewing these matters in light of the requirements of the United States Foreign Corrupt Practices Act. We have produced documents to the SEC both voluntarily and pursuant to a subpoena, and intend to make our employees available to the SEC for testimony. In addition, we understand that A. Jack Stanley, who most recently served as a consultant and chairman of Kellogg Brown & Root, has received a subpoena from the SEC.
TSKJ and other similarly owned entities entered into various contracts to build and expand the liquefied natural gas project for Nigeria LNG Limited, which is owned by the Nigerian National Petroleum Corporation, Shell Gas B.V., Cleag Limited (an affiliate of Total), and Agip International B.V. TSKJ is a private limited liability company registered in Madeira, Portugal whose members are Technip SA of France, Snamprogetti Netherlands B.V., which is an affiliate of ENI SpA of Italy, JGC Corporation of Japan, and Kellogg Brown & Root, each of which owns 25% of the venture.
It has been reported in the French press that the French magistrate has officially placed Jeffrey Tesler, an agent of TSKJ, under investigation for corruption of a foreign public official. In Nigeria, a legislative committee of the National Assembly and the Economic and Financial Crimes Commission, which is organized as part of the executive branch of the government, are also investigating these matters. Our representatives have met with the French magistrate and Nigerian officials and expressed our willingness to cooperate with those investigations.
In June 2004, we terminated all relationships with Mr. Stanley and another consultant and former employee of M.W. Kellogg, Ltd., a joint venture in which Kellogg Brown & Root has a 55% interest. The terminations occurred because of violations of our code of business conduct that allegedly involve the receipt of improper personal benefits in connection with TSKJ's construction of the natural gas liquefaction facility in Nigeria. We understand that the Department of Justice has expanded its investigation to include whether Mr. Stanley may have received payments in connection with bidding practices on certain foreign projects. We also understand that the matters under investigation by the Department of Justice involve parties other than Kellogg Brown & Root and M.W. Kellogg, Ltd. and cover an extended period of time, in some cases significantly before our acquisition of Dresser I ndustries in 1998.
 
  64  

 
Our investigation of these matters is too preliminary to determine any impact they may have on us. We have engaged outside counsel to investigate any allegations and are cooperating with the United States government's inquiries. There can be no assurance that the government's or our investigation will not conclude that violations of applicable laws have occurred.
As of June 30, 2004, we had not accrued any amounts related to these investigations.
Office of Foreign Assets Control inquiry
We have a Cayman Islands subsidiary with operations in Iran, and other European subsidiaries that manufacture goods destined for Iran and/or render services in Iran. The United States imposes trade restrictions and economic embargoes that prohibit United States incorporated entities and United States citizens and residents from engaging in commercial, financial, or trade transactions with some foreign countries, including Iran, unless authorized by the Office of Foreign Assets Control (OFAC) of the United States Treasury Department or exempted by statute.
We received and responded to an inquiry in mid-2001 from OFAC with respect to the operations in Iran by a Halliburton subsidiary that is incorporated in the Cayman Islands. The OFAC inquiry requested information with respect to compliance with the Iranian Transaction Regulations. Our 2001 written response to OFAC stated that we believed that we were in full compliance with applicable sanction regulations. In January 2004, we received a follow-up letter from OFAC requesting additional information. We responded fully to this request on March 19, 2004. We understand this matter has now been referred by OFAC to the Department of Justice. In July 2004, we received from an Assistant United States Attorney for the Southern District of Texas a grand jury subpoena requesting the production of documents. We intend to cooperate with the government’s investigation. As of June 30, 2004, we ha d not accrued any amounts related to this investigation.
Separate from the OFAC inquiry, we completed a study in 2003 of our activities in Iran during 2002 and 2003 and concluded that these activities were in full compliance with applicable sanction regulations. These sanction regulations require isolation of entities that conduct activities in Iran from contact with United States citizens or managers of United States companies.
We have been asked to and could be required to respond to other questions and inquiries about operations in countries with trade restrictions and economic embargoes.

Liquidity
Working capital requirements related to Iraq work
We expect a general decline in our working capital requirements during the second half of the year, primarily due to the transfer of the civilian fuel delivery work to the Defense Energy Support Center, the completion of the RIO I project, the leveling off of the LogCAP project work after the initial ramp-up in 2003, and the sale of accounts receivable related to RIO I, PCO Oil South, and LogCAP. See Note 6 to the condensed consolidated financial statements for more information. As described in “Legal Matters - Audits and inquiries about government contracts work” above, it is possible that we may, or may be required to, withhold additional invoicing or make refunds to our customer related to the DCAA’s review of additional aspects of our services, some of which could be substantial, until these matters are resolved. This could materially and adversely affect our liquid ity.
Credit facilities
The plan of reorganization through which the proposed settlement would be implemented will require us to contribute up to approximately $2.3 billion in cash to the trusts established for the benefit of asbestos and silica claimants pursuant to the United States Bankruptcy Code. We may need to finance additional amounts in connection with the settlement.
In connection with the proposed plan of reorganization, in the fourth quarter of 2003 we entered into:
-   a secured master letter of credit facility (Master LC Facility) intended to ensure that existing letters of credit supporting our contracts remain in place during the Chapter 11 proceedings, which allows advances until December 31, 2004 or the exit date of our Chapter 11 proceedings, with repayments due June 30, 2005; and
 
  65  

 
-   a secured $700 million three-year revolving credit facility for general working capital purposes, which matures in October 2006.
In July 2004, we entered into an additional secured $500 million 364-day revolving credit facility for general working capital purposes with terms substantially similar to our $700 million revolving credit facility.
Advances under the Master LC Facility will remain available until the earlier of December 31, 2004 or when an order confirming the proposed plan of reorganization becomes final and nonappealable. On such date, all advances outstanding under the Master LC Facility, if any, will become term loans payable in full on June 30, 2005, unless prepaid prior to such date, and all undrawn facility letters of credit shall cease to be subject to the terms of the Master LC Facility.
We experience increased working capital requirements from time to time associated with our business. An increased demand for working capital could affect our liquidity needs and could impair our ability to finance the proposed settlement on acceptable terms.
Letters of credit
We entered into a master letter of credit facility in the fourth quarter of 2003 that is intended to replace any cash collateralization rights of issuers of substantially all our existing letters of credit during the pendency of the Chapter 11 proceedings of DII Industries, Kellogg Brown & Root, and our other filing subsidiaries. The master letter of credit facility is now in effect and governs at least 90% of the face amount of our existing letters of credit.
Under the master letter of credit facility, if any letters of credit that are covered by the facility are drawn on or before December 31, 2004, the facility will provide the cash needed for such draws, as well as for any collateral or reimbursement obligations, in respect thereof, with any such borrowings being converted into term loans. However, with respect to the letters of credit that are not subject to the master letter of credit facility, we could be subject to reimbursement and cash collateral obligations. In addition, if the proposed plan of reorganization does not become effective in accordance with its terms by December 31, 2004 and we are unable to negotiate a renewal or extension of the master letter of credit facility, the letters of credit that are now governed by that facility will be governed by the arrangements with the banks that existed prior to the effectiveness of the facility. In many cases, those pre-existing arrangements impose reimbursement and/or cash collateral obligations on us and/or our subsidiaries.
Uncertainty may also hinder our ability to access new letters of credit in the future. This could impede our liquidity and/or our ability to conduct normal operations.
Credit ratings
Investment grade ratings are BBB– or higher for Standard & Poor’s and Baa3 or higher for Moody’s. Our current ratings are one level above BBB– on Standard & Poor’s and one level above Baa3 on Moody’s. In December 2003, Standard & Poor’s revised its credit watch listing for us from ‘‘negative’’ to ‘‘developing’’ in response to our announcement that DII Industries, Kellogg Brown & Root, and other of our subsidiaries filed Chapter 11 proceedings to implement the proposed asbestos and silica settlement. In May 2004, Moody’s Investors Service confirmed its ratings, but revised its outlook from ‘‘positive’’ to ‘‘stable.’’
If our debt rating falls below investment grade, we will be required to provide additional collateral to secure our credit facilities. With respect to the outstanding letters of credit that are not subject to the master letter of credit facility, we may be in technical breach of the bank agreements governing those letters of credit and we may be required to reimburse the bank for any draws or provide cash collateral to secure those letters of credit. In addition, if the proposed plan of reorganization does not become effective in accordance with its terms by December 31, 2004 and we are unable to negotiate a renewal or extension of the terms of the master letter of credit facility, advances under our master letter of credit facility will no longer be available and will no longer override the reimbursement, cash collateral, or other agreements or arrangements relating to any of the let ters of credit that existed prior to the effectiveness of the master letter of credit facility. In that event, we may be required to provide reimbursement for any draws or cash collateral to secure our or our subsidiaries’ obligations under arrangements in place prior to our entering into the master letter of credit facility.
 
  66  

 
In addition, our elective deferral compensation plan has a provision which states that if the Standard & Poor’s credit rating falls below BBB, the amounts credited to participants’ accounts will be paid to participants in a lump sum within 45 days. At June 30, 2004, this amount was approximately $55 million.
In the event our debt ratings are lowered by either agency, we may have to issue additional debt or equity securities or obtain additional credit facilities in order to meet our liquidity needs. We anticipate that any such new financing or credit facilities would not be on terms as attractive as those we have currently and that we would also be subject to increased costs of capital and interest rates. We also may be required to provide cash collateral to obtain surety bonds or letters of credit, which would reduce our available cash or require additional financing. Further, if we are unable to obtain financing for our proposed plan of reorganization on terms that are acceptable to us, we may be unable to complete the proposed plan of reorganization.

Geopolitical and International Events
International and Political Events
A significant portion of our revenue is derived from our non-United States operations, which exposes us to risks inherent in doing business in each of the more than 100 other countries in which we transact business. The occurrence of any of the risks described below could have a material adverse effect on our consolidated results of operations and consolidated financial condition.
Our operations in more than 100 countries other than the United States accounted for approximately 74% of our consolidated revenues during the first six months of 2004 and 73% of our consolidated revenues during 2003. Operations in countries other than the United States are subject to various risks peculiar to each country. With respect to any particular country, these risks may include:
-   expropriation and nationalization of our assets in that country;
-   political and economic instability;
-   social unrest, acts of terrorism, force majeure, war, or other armed conflict;
-   inflation;
-   currency fluctuations, devaluations, and conversion restrictions;
-   confiscatory taxation or other adverse tax policies;
-   governmental activities that limit or disrupt markets, restrict payments, or limit the movement of funds;
-   governmental activities that may result in the deprivation of contract rights; and
-   trade restrictions and economic embargoes imposed by the United States and other countries, including current restrictions on our ability to provide products and services to Iran and Syria, which are significant producers of oil and gas.
Due to the unsettled political conditions in many oil-producing countries and countries in which we provide governmental logistical support, our revenues and profits are subject to the adverse consequences of war, the effects of terrorism, civil unrest, strikes, currency controls, and governmental actions. Countries where we operate that have significant amounts of political risk include: Afghanistan, Algeria, Argentina, Indonesia, Iran, Iraq, Nigeria, Russia, and Venezuela. In addition, military action or continued unrest in the Middle East could impact the demand and pricing for oil and gas, disrupt our operations in the region and elsewhere, and increase our costs for security worldwide. In addition, investigations by governmental authorities (see “Legal Matters - Nigerian joint venture” above), as well as the social, economic, and political climate in Nigeria, could mate rially and adversely affect our Nigerian business and operations.
Military Action, Other Armed Conflicts, or Terrorist Attacks
Military action in Iraq, increasing military tension involving North Korea, as well as the terrorist attacks of September 11, 2001 and subsequent terrorist attacks, threats of attacks, and unrest, have caused instability in the world’s financial and commercial markets and have significantly increased political and economic instability in some of the geographic areas in which we operate. Acts of terrorism and threats of
 
  67  

 
armed conflicts in or around various areas in which we operate, such as the Middle East and Indonesia, could limit or disrupt markets and our operations, including disruptions resulting from the evacuation of personnel, cancellation of contracts, or the loss of personnel or assets.
Such events may cause further disruption to financial and commercial markets and may generate greater political and economic instability in some of the geographic areas in which we operate. In addition, any possible reprisals as a consequence of the war with and ongoing military action in Iraq, such as acts of terrorism in the United States or elsewhere, could materially and adversely affect us in ways we cannot predict at this time.
Taxation
We have operations in more than 100 countries other than the United States and as a result are subject to taxation in many jurisdictions. Therefore, the final determination of our tax liabilities involves the interpretation of the statutes and requirements of taxing authorities worldwide. Foreign income tax returns of foreign subsidiaries, unconsolidated affiliates, and related entities are routinely examined by foreign tax authorities. These tax examinations may result in assessments of additional taxes or penalties or both. Additionally, new taxes, such as the proposed excise tax in the United States targeted at heavy equipment of the type we own and use in our operations, could negatively affect our results of operations.
Foreign Exchange and Currency Risks
A sizable portion of our consolidated revenues and consolidated operating expenses are in foreign currencies. As a result, we are subject to significant risks, including:
-   foreign exchange risks resulting from changes in foreign exchange rates and the implementation of exchange controls such as those experienced in Argentina in late 2001 and early 2002; and
-   limitations on our ability to reinvest earnings from operations in one country to fund the capital needs of our operations in other countries.
We conduct business in countries that have nontraded or “soft” currencies which, because of their restricted or limited trading markets, may be more difficult to exchange for “hard” currency. We may accumulate cash in soft currencies and we may be limited in our ability to convert our profits into United States dollars or to repatriate the profits from those countries.
We selectively use hedging transactions to limit our exposure to risks from doing business in foreign currencies. For those currencies that are not readily convertible, our ability to hedge our exposure is limited because financial hedge instruments for those currencies are nonexistent or limited. Our ability to hedge is also limited because pricing of hedging instruments, where they exist, is often volatile and not necessarily efficient.
In addition, the value of the derivative instruments could be impacted by:
-   adverse movements in foreign exchange rates;
-   interest rates;
-   commodity prices; or
-   the value and time period of the derivative being different than the exposures or cash flows being hedged.

Customers and Business
Exploration and Production Activity
Demand for our services and products depends on oil and natural gas industry activity and expenditure levels that are directly affected by trends in oil and natural gas prices. A prolonged downturn in oil and gas prices could have a material adverse effect on our consolidated results of operations and consolidated financial condition.
Demand for our products and services is particularly sensitive to the level of development, production, and exploration activity of, and the corresponding capital spending by, oil and natural gas companies, including national oil companies. Prices for oil and natural gas are subject to large fluctuations in response to relatively minor changes in the supply of and demand for oil and natural gas, market
 
  68  

 
uncertainty, and a variety of other factors that are beyond our control. Any prolonged reduction in oil and natural gas prices will depress the level of exploration, development, and production activity, often reflected as changes in rig counts. Lower levels of activity result in a corresponding decline in the demand for our oil and natural gas well services and products that could have a material adverse effect on our revenues and profitability. Factors affecting the prices of oil and natural gas include:
-   governmental regulations;
-   global weather conditions;
-   worldwide political, military, and economic conditions, including the ability of OPEC to set and maintain production levels and prices for oil;
-   the level of oil production by non-OPEC countries;
-   the policies of governments regarding the exploration for and production and development of their oil and natural gas reserves;
-   the cost of producing and delivering oil and gas; and
-   the level of demand for oil and natural gas, especially demand for natural gas in the United States.
Historically, the markets for oil and gas have been volatile and are likely to continue to be volatile in the future. Spending on exploration and production activities and capital expenditures for refining and distribution facilities by large oil and gas companies have a significant impact on the activity levels of our businesses.
Barracuda-Caratinga Project
See Note 3 to the condensed consolidated financial statements for a discussion of this project and the April 2004 agreement in principle and “Fixed-Price Engineering and Construction Projects” below.
If the April 2004 agreement in principle between us and Petrobras is not implemented we would remain subject to the November 2003 agreements in which the project owner agreed to:
-   pay $69 million to settle a portion of our claims, thereby reducing the amount of probable unapproved claims to $114 million;
-   extend the original project completion dates and other milestone dates, reducing our exposure to liquidated damages; and
-   delay Kellogg Brown & Root’s repayment of approximately $300 million in advance payments until December 2004, although we and the project owner did not resolve whether Kellogg Brown & Root would be obligated to pay interest on this amount.
In addition, we would remain subject to the following risks under the November 2003 agreements:
Unapproved Claims. We have asserted claims for compensation substantially in excess of the $114 million of probable unapproved claims, as well as claims for additional time to complete the project before liquidated damages become applicable. The project owner and Petrobras asserted claims against us that are in addition to the project owner’s potential claims for liquidated damages. In the November 2003 agreements, the parties agreed to arbitrate these remaining disputed claims. In addition, we agreed to cap our financial recovery to a maximum of $375 million, and the project owner and Petrobras agreed to cap their recovery to a maximum of $380 million plus liquidated damages.
Liquidated Damages. In the event that any portion of the project delay is determined to be attributable to us and any phase of the project is completed after the milestone dates specified in the contract, we could be required to pay liquidated damages. These damages were initially (prior to the November 2003 agreements) calculated on an escalating basis rising ultimately to approximately $1 million per day of delay caused by us, subject to a total cap on liquidated damages of 10% of the final contract amount, yielding a cap of approximately $272 million as of June 30, 2004.
Under the November 2003 agreements, the project owner granted an extension of time to the original completion dates and other milestone dates that average approximately 12 months. In addition, the project owner agreed to delay any attempt to assess the original liquidated damages against us for project delays beyond 12 months and up to 18 months and delay any drawing of letters of credit with respect to such liquidated damages until the earliest of December 7, 2004, the completion of any arbitration
 
  69  

 
proceedings or the resolution of all claims between the project owner and us. Although the November 2003 agreements do not delay the drawing of letters of credit for liquidated damages for delays beyond 18 months, our master letter of credit facility will provide funding for any such draw before December 31, 2004. The November 2003 agreements also provide for a separate liquidated damages calculation of $450,000 per day for each of the Barracuda and the Caratinga vessels if delayed beyond 18 months from the original schedule. That amount is subject to the total cap on liquidated damages of 10% of the final contract amount. Based upon the November 2003 agreements and our June 2004 project forecasts, we estimate that if we were to be completely unsuccessful in our claims for additional time, we would be obligated to pay approximately $244 million in liquidated damages. If the April 2004 agreement in principle were not finalized, based on June 2004 project forecasts, Kellogg Brown & Root could be subject to an additional approximately $159 million in liquidated damages beyond the $85 million of liquidated damages recorded as of June 30, 2004 in the event that the delay in the project is determined to be attributable to us. There can be no assurance that further project delays will not occur.
Value added taxes. On December 16, 2003, the State of Rio de Janeiro issued a decree recognizing that Petrobras is entitled to a credit for the value added taxes paid on the project. The decree also provided that value added taxes that may have become due on the project, but which had not yet been paid could be paid in January 2004 without penalty or interest. In response to the decree, Petrobras agreed to:
-   directly pay the value added taxes due on all imports on the project (including Petrobras’ January 2004 payment of approximately $150 million); and
-   reimburse us for value added taxes paid on local purchases, of which approximately $100 million will become due during 2004.
Since the credit to Petrobras for these value added taxes is on a delayed basis, the issue of whether we must bear the cost of money for the period from payment by Petrobras until receipt of the credit has not been determined.
The validity of the December 2003 decree has now been challenged in court in Brazil. Our legal advisers in Brazil believe that the decree will be upheld. If it is overturned or rescinded, or the Petrobras credits are lost for any other reason not due to Petrobras, the issue of who must ultimately bear the cost of the value added taxes will have to be determined based upon the law prior to the December 2003 decree. We believe that the value added taxes are reimbursable under the contract and prior law, but, until the December 2003 decree was issued, Petrobras and the project owner had been contesting the reimbursability of up to $227 million of value added taxes. There can be no assurance that we will not be required to pay all or a portion of these value added taxes. In addition, penalties and interest of $40 million to $100 million could be due if the December 2003 decree is invalida ted. We have paid $8 million for these amounts as of June 30, 2004.
Governmental and Capital Spending
Our business is directly affected by changes in governmental spending and capital expenditures by our customers. Some of the changes that may materially and adversely affect us include:
-   a decrease in the magnitude of governmental spending and outsourcing for military and logistical support of the type that we provide. For example, the current level of government services being provided in the Middle East may not continue for an extended period of time;
-   an increase in the magnitude of governmental spending and outsourcing for military and logistical support, which can materially and adversely affect our liquidity needs as a result of additional or continued working capital requirements to support this work;
-   a decrease in capital spending by governments for infrastructure projects of the type that we undertake;
-   the consolidation of our customers, which has:
 
  70  

 
           -   caused customers to reduce their capital spending, which has in turn reduced the demand for our services and products; and
           -   resulted in customer personnel changes, which in turn affects the timing of contract negotiations and settlements of claims and claim negotiations with engineering and construction customers on cost variances and change orders on major projects;
-   adverse developments in the business and operations of our customers in the oil and gas industry, including write-downs of reserves and reductions in capital spending for exploration, development, production, processing, refining, and pipeline delivery networks; and
-   ability of our customers to timely pay the amounts due us.
Customers
Both our Energy Services Group and KBR depend on a limited number of significant customers. While, except for the United States Government, none of these customers represented more than 10% of consolidated revenues in any period presented, the loss of one or more significant customers could have a material adverse effect on our business and our consolidated results of operations.
Acquisitions, Dispositions, Investments, and Joint Ventures
We may actively seek opportunities to maximize efficiency and value through various transactions, including purchases or sales of assets, businesses, investments or contractual arrangements or joint ventures. These transactions would be intended to result in the realization of savings, the creation of efficiencies, the generation of cash or income, or the reduction of risk. Acquisition transactions may be financed by additional borrowings or by the issuance of our common stock. These transactions may also affect our consolidated results of operations.
These transactions also involve risks and we cannot ensure that:
-   any acquisitions would result in an increase in income;
-   any acquisitions would be successfully integrated into our operations;
-   any disposition would not result in decreased earnings, revenue, or cash flow;
-   any dispositions, investments, acquisitions, or integrations would not divert management resources; or
-   any dispositions, investments, acquisitions, or integrations would not have a material adverse effect on our results of operations or financial condition.
We conduct some operations through joint ventures, where control may be shared with unaffiliated third parties. As with any joint venture arrangement, differences in views among the joint venture participants may result in delayed decisions or in failures to agree on major issues. We also cannot control the actions of our joint venture partners, including any nonperformance, default, or bankruptcy of our joint venture partners. These factors could potentially materially and adversely affect the business and operations of the joint venture and, in turn, our business and operations.
Fixed-Price Engineering and Construction Projects
We contract to provide services either on a time-and-materials basis or on a fixed-price basis, with fixed-price (or lump-sum) contracts accounting for approximately 12% of KBR’s revenue for the first half of 2004 and 24% for the year ended December 31, 2003. We bear the risk of cost overruns, operating cost inflation, labor availability and productivity, and supplier and subcontractor pricing and performance in connection with projects covered by fixed-price contracts. Our failure to estimate accurately the resources and time required for a fixed-price project, or our failure to complete our contractual obligations within the time frame and costs committed, could have a material adverse effect on our business, results of operations, and financial condition.
Environmental Requirements
Our businesses are subject to a variety of environmental laws, rules, and regulations in the United States and other countries, including those covering hazardous materials and requiring emission performance standards for facilities. For example, our well service operations routinely involve the
 
  71  

 
handling of significant amounts of waste materials, some of which are classified as hazardous substances. We also store, transport, and use radioactive and explosive materials in certain of our operations. Environmental requirements include, for example, those concerning:
-   the containment and disposal of hazardous substances, oilfield waste, and other waste materials;
-   the importation and use of radioactive materials;
-   the use of underground storage tanks; and
-   the use of underground injection wells.
Environmental and other similar requirements generally are becoming increasingly strict. Sanctions for failure to comply with these requirements, many of which may be applied retroactively, may include:
-   administrative, civil, and criminal penalties;
-   revocation of permits to conduct business; and
-   corrective action orders, including orders to investigate and/or clean up contamination.
Failure on our part to comply with applicable environmental requirements could have a material adverse effect on our consolidated financial condition. We are also exposed to costs arising from environmental compliance, including compliance with changes in or expansion of environmental requirements, such as the potential regulation in the United States of our Energy Services Group’s hydraulic fracturing services and products as underground injection, which could have a material adverse effect on our business, financial condition, operating results, or cash flows.
We are exposed to claims under environmental requirements and, from time to time such claims have been made against us. In the United States, environmental requirements and regulations typically impose strict liability. Strict liability means that in some situations we could be exposed to liability for cleanup costs, natural resource damages, and other damages as a result of our conduct that was lawful at the time it occurred or the conduct of prior operators or other third parties. Liability for damages arising as a result of environmental laws could be substantial and could have a material adverse effect on our consolidated results of operations.
Changes in environmental requirements may negatively impact demand for our services. For example, oil and natural gas exploration and production may decline as a result of environmental requirements (including land use policies responsive to environmental concerns). Such a decline, in turn, could have a material adverse effect on us.
Intellectual Property Rights
We rely on a variety of intellectual property rights that we use in our products and services. We may not be able to successfully preserve these intellectual property rights in the future and these rights could be invalidated, circumvented, or challenged. In addition, the laws of some foreign countries in which our products and services may be sold do not protect intellectual property rights to the same extent as the laws of the United States. Our failure to protect our proprietary information and any successful intellectual property challenges or infringement proceedings against us could materially and adversely affect our competitive position.
Technology
The market for our products and services is characterized by continual technological developments to provide better and more reliable performance and services. If we are not able to design, develop, and produce commercially competitive products and to implement commercially competitive services in a timely manner in response to changes in technology, our business and revenue could be materially and adversely affected and the value of our intellectual property may be reduced. Likewise, if our proprietary technologies, equipment and facilities, or work processes become obsolete, we may no longer be competitive and our business and revenue could be materially and adversely affected.
Systems
Our business could be materially and adversely affected by problems encountered in the installation of a new financial system to replace the current systems for our Engineering and Construction Group.
 
  72  

 
Technical Personnel
Many of the services that we provide and the products that we sell are complex and highly engineered and often must perform or be performed in harsh conditions. We believe that our success depends upon our ability to employ and retain technical personnel with the ability to design, utilize, and enhance these products and services. In addition, our ability to expand our operations depends in part on our ability to increase our skilled labor force. The demand for skilled workers is high and the supply is limited. A significant increase in the wages paid by competing employers could result in a reduction of our skilled labor force, increases in the wage rates that we must pay, or both. If either of these events were to occur, our cost structure could increase, our margins could decrease, and our growth potential could be impaired.
Weather
Our businesses could be materially and adversely affected by severe weather, particularly in the Gulf of Mexico where we have significant operations. Repercussions of severe weather conditions may include:
-   evacuation of personnel and curtailment of services;
-   weather-related damage to offshore drilling rigs resulting in suspension of operations;
-   weather-related damage to our facilities;
-   inability to deliver materials to jobsites in accordance with contract schedules; and
-   loss of productivity.
Because demand for natural gas in the United States drives a disproportionate amount of our Energy Services Group’s United States business, warmer than normal winters in the United States are detrimental to the demand for our services to gas producers.
 
  73  

 
Item 3. Quantitative and Qualitative Disclosures about Market Risk
We are exposed to financial instrument market risk from changes in foreign currency exchange rates, interest rates, and, to a limited extent, commodity prices. We selectively manage these exposures through the use of derivative instruments to mitigate our market risk from these exposures. The objective of our risk management is to protect our cash flows related to sales or purchases of goods or services from market fluctuations in currency rates. Our use of derivative instruments includes the following types of market risk:
-   volatility of the currency rates;
-   time horizon of the derivative instruments;
-   market cycles; and
-   the type of derivative instruments used.
In the first quarter of 2004, we entered into derivative instruments, including put options, swaps, and collared options, as cash flow hedges against price variability of oil and natural gas. At June 30, 2004, the fair value of these instruments was not material.
We do not use derivative instruments for trading purposes. We do not consider any of these risk management activities to be material.

Item 4. Controls and Procedures
In accordance with Exchange Act Rules 13a-15 and 15d-15, we carried out an evaluation, under the supervision and with the participation of management, including our Chief Executive Officer and Chief Financial Officer, of the effectiveness of our disclosure controls and procedures as of the end of the period covered by this report. Based on that evaluation, our Chief Executive Officer and Chief Financial Officer concluded that our disclosure controls and procedures were effective as of June 30, 2004 to provide reasonable assurance that information required to be disclosed in our reports filed or submitted under the Exchange Act is recorded, processed, summarized and reported within the time periods specified in the Securities and Exchange Commission’s rules and forms. Our disclosure controls and procedures include controls and procedures designed to ensure that information require d to be disclosed in reports filed or submitted under the Exchange Act is accumulated and communicated to our management, including our Chief Executive Officer and Chief Financial Officer, as appropriate, to allow timely decisions regarding required disclosure.
There has been no change in our internal controls over financial reporting that occurred during the three months ended June 30, 2004 that has materially affected, or is reasonably likely to materially affect, our internal controls over financial reporting.
 
  74  

 
PART II. OTHER INFORMATION

Item 1. Legal Proceedings

Information relating to various commitments and contingencies is described in “Management’s Discussion and Analysis of Financial Condition and Results of Operations,” in “Forward-Looking Information and Risk Factors,” and in Notes 3, 12, 13, and 14 to the condensed consolidated financial statements.

Item 2. Changes in Securities, Use of Proceeds, and Issuer Purchases of Equity Securities

Following is a summary of our repurchases of our common stock during the three-month period ended June 30, 2004.

 
 
 
 
Total Number of Shares
Maximum Number of
 
 
 
 
Purchased as Part of
Shares That May Yet
 
 
Total Number of
Average Price
Publicly Announced
Be Purchased Under
Period
 
Shares Purchased (a)
Paid per Share
Plans or Programs
Plans or Programs (b)

 



 
   
 
   
 
   
 
   
 
 
April 1-30
   
17,438
 
$
30.47
   
-
   
-
 
May 1-31
   
6,317
 
$
30.88
   
-
   
-
 
June 1-30
   
2,991
 
$
30.62
   
-
   
-
 

 
 
 
 
 
Total
   
26,746
 
$
30.58
   
-
   
22,385,700
 

 
 
 
 
 

(a)   All of the shares repurchased during the three-month period ended June 30, 2004 were acquired from employees in connection with the settlement of income tax and related benefit withholding obligations arising from vesting in restricted stock grants. These share purchases were not part of a publicly announced program to purchase common shares.
(b)   On April 25, 2000, our Board of Directors approved plans to implement a share repurchase program for up to 44 million shares of our common stock.

Item 3. Defaults Upon Senior Securities

None.

Item 4. Submission of Matters to a Vote of Security Holders

At our Annual Meeting of Stockholders held on May 19, 2004, stockholders were asked to consider and act upon:

(1)   the election of Directors for the ensuing year;
(2)   a proposal to amend Halliburton’s Certificate of Incorporation to increase authorized common stock;
(3)   a stockholder proposal on operations in Iran;
(4)   a stockholder proposal on Director election vote threshold; and
(5)   a stockholder proposal to separate Chairman and CEO.

The following table sets out, for each matter where applicable, the number of votes cast for, against, or withheld, as well as the number of abstentions and broker non-votes.
 
  75  

 
(1)   Election of Directors:

Name of Nominee
 
Votes For
Votes Withheld

 

 
   
 
   
 
 
Robert L. Crandall
   
370,368,906
   
17,090,988
 
Kenneth T. Derr
   
371,240,669
   
16,219,225
 
Charles J. DiBona
   
374,964,569
   
12,495,325
 
W. R. Howell
   
370,744,065
   
16,715,829
 
Ray L. Hunt
   
370,731,836
   
16,728,058
 
David J. Lesar
   
373,418,898
   
14,040,996
 
Aylwin B. Lewis
   
375,170,256
   
12,289,638
 
J. Landis Martin
   
374,785,305
   
12,674,589
 
Jay A. Precourt
   
375,055,635
   
12,404,259
 
Debra L. Reed
   
375,217,385
   
12,242,509
 
C. J. Silas
   
365,835,957
   
21,623,937
 

(2)Proposal to amend Halliburton’s Certificate of Incorporation to increase authorized common stock:

Number of Votes For
   
353,686,782
 
Number of Votes Against
   
27,166,951
 
Number of Votes Abstain
   
6,606,161
 
Number of Broker Non-Votes
   
0
 

(3)   Stockholder proposal on operations in Iran:

Number of Votes For
   
21,894,115
 
Number of Votes Against
   
273,848,104
 
Number of Votes Abstain
   
34,536,560
 
Number of Broker Non-Votes
   
57,181,115
 

(4)   Stockholder proposal on director election threshold:

Number of Votes For
   
43,102,336
 
Number of Votes Against
   
280,302,337
 
Number of Votes Abstain
   
6,874,105
 
Number of Broker Non-Votes
   
57,181,116
 

(5)Stockholder proposal on separate Chairman and CEO:

Number of Votes For
   
47,734,694
 
Number of Votes Against
   
277,340,181
 
Number of Votes Abstain
   
5,203,904
 
Number of Broker Non-Votes
   
57,181,115
 

Item 5. Other Information

None.
 
  76  

 
Item 6. Exhibits and Reports on Form 8-K

(a)   Exhibits

   3.1   Restated Certificate of Incorporation of Halliburton Company filed with the Secretary of State of Delaware on May 21, 2004 (incorporated by reference to Exhibit 3.1 of Halliburton’s Registration Statement on Form S-4 filed on July 19, 2004, Registration No. 333-112977.)

   10.1   Amendment No. 1 dated as of July 14, 2004 to the 3-Year Revolving Credit Agreement, dated as of October 31, 2003, among Halliburton, the Banks party thereto, Citicorp North America, Inc., as Administrative Agent, JPMorgan Chase Bank, as Syndication Agent, and ABN AMRO Bank N.V., as Documentation Agent (incorporated by reference to Exhibit 10.1(a) of Halliburton’s Registration Statement on Form S-4 filed on July 19, 2004, Registration No. 333-112977.)

   10.2   Amendment No. 1 dated as of May 10, 2004 to Master Letter of Credit Facility Agreement, dated as of October 31, 2003, among Halliburton, Kellogg Brown & Root, Inc., and DII Industries, LLC, as Account Parties, the Banks party thereto, and Citicorp North America, Inc., as Administrative Agent, JPMorgan Chase Bank, as Syndication Agent, and ABN AMRO Bank N.V., as Documentation Agent, as amended (incorporated by reference to Exhibit 10.4 of Halliburton’s Registration Statement on Form S-4 filed on June 3, 2004, Registration No. 333-112977.)

   10.3   Amendment No. 2 dated as of July 14, 2004 to Master Letter of Credit Facility Agreement, dated as of October 31, 2003, among Halliburton, Kellogg Brown & Root, Inc., and DII Industries, LLC, as Account Parties, the Banks party thereto, Citicorp North America, Inc., as Administrative Agent, JPMorgan Chase Bank, as Syndication Agent, and ABN AMRO Bank N.V., as Documentation Agent, as amended (incorporated by reference to Exhibit 10.2(a) of Halliburton’s Registration Statement on Form S-4 filed on July 19, 2004, Registration No. 333-112977.)

   10.4   364-Day Revolving Credit Agreement, dated as of July 14, 2004, among Halliburton, the Issuing Banks and Banks party thereto, Citicorp North America, Inc., as Paying Agent and as Co-Administrative Agent, JPMorgan Chase Bank, as Co-Administrative Agent, ABN AMRO Bank N.V., as Syndication Agent, HSBC Bank USA, National Association and The Royal Bank of Scotland plc, as Co-Documentation Agents (incorporated by reference to Exhibit 10.3 of Halliburton’s Registration Statement on Form S-4 filed on July 19, 2004, Registration No. 333-112977.)

*   10.5   Halliburton Company 1993 Stock and Incentive Plan, as amended and restated effective May 18, 2004.

*   12   Statement of Computation of Ratio of Earnings to Fixed Charges.

*   31.1   Certification of Chief Executive Officer pursuant to Section 302 of the Sarbanes-Oxley Act of 2002.

*   31.2   Certification of Chief Financial Officer pursuant to Section 302 of the Sarbanes-Oxley Act of 2002.
 
  77  

 
**   32.1   Certification of Chief Executive Officer pursuant to Section 906 of the Sarbanes-Oxley Act of 2002.

**   32.2   Certification of Chief Financial Officer pursuant to Section 906 of the Sarbanes-Oxley Act of 2002.

*   Filed with this Form 10-Q
**   Furnished with this Form 10-Q

(b)    Reports on Form 8-K:

 
Date Filed
Date of
Earliest Event
 
Description of Event



 
 
 
During the second quarter of 2004:
 
 
 
April 20, 2004
April 19, 2004
Item 9. Regulation FD Disclosure for a press release announcing the agreement in principle with Petrobras on the Barracuda-Caratinga project.
 
 
 
April 30, 2004
April 28, 2004
Item 12. Disclosure of Results of Operations and Financial Condition for a press release announcing the 2004 first quarter results.
 
 
 
May 5, 2004
May 5, 2004
Item 5. Other Events announcing the amendment of the Company’s Corporate Governance Guidelines.
 
 
 
May 11, 2004
May 10, 2004
Item 9. Regulation FD Disclosure for a press release announcing completion of hearings on confirmation of DII Industries’ proposed plan of reorganization and anticipated agreements with certain insurance companies.
 
 
 
May 20, 2004
May 19, 2004
Item 9. Regulation FD Disclosure for a press release announcing a 2004 second quarter dividend and results of the annual shareholders’ meeting.
 
 
 
May 21, 2004
May 18, 2004
Item 5. Other Events announcing the Defense Contract Audit Agency has recommended suspension of a portion of KBR’s billings for dining facility costs in Iraq.
 
Item 9. Regulation FD Disclosure for a press release reporting that Halliburton continues to work with the United States government to resolve billing issues.
 
 
 
June 14, 2004
June 11, 2004
Item 5. Other Events for a press release announcing the United States Securities and Exchange Commission investigation regarding a Nigerian joint venture.
 
  78  

 

 
Date Filed
Date of
Earliest Event
 
Description of Event



 
 
 
During the second quarter of 2004 (continued):
 
 
 
June 18, 2004
June 18, 2004
Item 5. Other Events announcing the termination of all relationships with A. Jack Stanley.
 
Item 9. Regulation FD Disclosure for a press release announcing the termination of all relationships with A. Jack Stanley.
 
 
 
June 22, 2004
June 18, 2004
Item 9. Regulation FD Disclosure for a press release announcing a conference call on July 23, 2004 to discuss 2004 second quarter results.
 
 
 
June 29, 2004
June 29, 2004
Item 5. Other Events for a press release announcing updates on the Barracuda-Caratinga project and agreements with insurance companies.

 
  79  

 

SIGNATURES


As required by the Securities Exchange Act of 1934, the registrant has authorized this report to be signed on behalf of the registrant by the undersigned authorized individuals.


   HALLIBURTON COMPANY



 
 
Date:   August 3, 2004
By: /s/   C. Christopher Gaut
 
C. Christopher Gaut
 
Executive Vice President and
 
Chief Financial Officer
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
/s/   Mark A. McCollum
 
   Mark A. McCollum
 
Senior Vice President and
 
Chief Accounting Officer


  80  
Unassociated Document

                                                       &n bsp;    Exhibit 10.5

HALLIBURTON COMPANY
1993 STOCK AND INCENTIVE PLAN
AS AMENDED AND RESTATED MAY 18, 2004
 
I.      PURPOSE
 
The purpose of the Halliburton Company 1993 Stock and Incentive Plan (the "Plan") is to provide a means whereby Halliburton Company, a Delaware corporation (the "Company"), and its Subsidiaries may attract, motivate and retain highly competent employees and to provide a means whereby selected employees can acquire and maintain stock ownership and receive cash awards, thereby strengthening their concern for the long-term welfare of the Company. The Plan is also intended to provide employees with additional incentive and reward opportunities designed to enhance the profitable growth of the Company over the long term. A further purpose of the Plan is to allow awards under the Plan to Non-employee Directors in order to enhance the Company's ability to attract and retain highly qualified Directors. Accordingly, the Plan provides for granting Incentive Stock Options, Options which do not constitute Incentive Stock Options, Stock Appreciation Rights, Restricted Stock Awards, Performance Awards, Stock Value Equivalent Awards, or any combination of the foregoing, as is best suited to the circumstances of the particular employee or Non-employee Director as provided herein. The Plan was established February 18, 1993, has been amended from time to time thereafter, and effective as of May 18, 2004, is amended and restated to add an expiration date for the granting of Awards under the Plan.
 
II.      DEFINITIONS
 
The following definitions shall be applicable throughout the Plan unless specifically modified by any paragraph:
 
(a)   "Award" means, individually or collectively, any Option, Stock Appreciation Right, Restricted Stock Award, Performance Award or Stock Value Equivalent Award.
 
(b)   "Award Document" means the relevant award agreement or other document containing the terms and conditions of an Award.
 
(c)   "Beneficial Owners" shall have the meaning set forth in Rule 13d-3 promulgated under the Exchange Act.
 
(d)   "Board" means the Board of Directors of Halliburton Company.
 
(e)   "Change of Control Value" means, for the purposes of Paragraph (f) of Article XII, the amount determined in Clause (i), (ii) or (iii), whichever is applicable, as follows: (i) the per share price offered to stockholders of the Company in any merger, consolidation, sale of assets or dissolution transaction, (ii) the per share price offered to stockholders of the Company in any tender offer or exchange offer whereby a Corporate Change takes place or (iii) if a Corporate Change occurs other than as described in Clause (i) or Clause (ii), the fair market value per share determined by the Committee as of the date determined by the Committee to be the date of cancellation and surrender of an Option or Stock Appreciation Right. If the consideration offered to stockholders of the Company in any transacti on described in this Paragraph (e) consists of anything other than cash, the Committee shall determine the fair cash equivalent of the portion of the consideration offered which is other than cash.
 
(f)   "Code" means the Internal Revenue Code of 1986, as amended. Reference in the Plan to any section of the Code shall be deemed to include any amendments or successor provisions to such section and any regulations under such section.
 
(g)   "Committee" means the committee selected by the Board to administer the Plan in accordance with Paragraph (a) of Article IV of the Plan.
 
 
  1  

 
 
(h)   "Common Stock" means the Common Stock, par value $2.50 per share, of the Company.
 
(i)   "Company" means Halliburton Company, a Delaware corporation.
 
(j)   "Corporate Change" shall conclusively be deemed to have occurred on a Corporate Change Effective Date if an event set forth in any one of the following paragraphs shall have occurred:
 
(i)   any Person is or becomes the Beneficial Owner, directly or indirectly, of securities of the Company (not including in the securities beneficially owned by such Person any securities acquired directly from the Company or its affiliates) representing 20% or more of the combined voting power of the Company's then outstanding securities; or
 
(ii)          the following individuals cease for any reason to constitute a majority of the number of directors then serving: individuals who, on the date hereof, constitute the Board and any new Director (other than a Director whose initial assumption of office is in connection with an actual or threatened election contest relating to the election of Directors of the Company) whose appointment or election by the Board or nomination for election by the Company's stockholders was approved or recommended by a vote of at least two-thirds (2/3) of the Directors then still in office who either were Directors on the date hereof or whose appointment, election or nomination for election was previously so approved or recommended; or
 
(iii)         there is consummated a merger or consolidation of the Company or any direct or indirect Subsidiary of the Company with any other corporation, other than (A) a merger or consolidation which would result in the voting securities of the Company outstanding immediately prior to such merger or consolidation continuing to represent (either by remaining outstanding or by being converted into voting securities of the surviving entity or any parent thereof), in combination with the ownership of any trustee or other fiduciary holding securities under an employee benefit plan of the Company or any Subsidiary of the Company, at least 50% of the combined voting power of the securities of the Company or such surviving entity or any parent thereof outstanding immediately after such merger or consolidation, or (B) a merge r or consolidation effected to implement a recapitalization of the Company (or similar transaction) in which no Person is or becomes the Beneficial Owner, directly or indirectly, of securities of the Company (not including in the securities Beneficially Owned by such Person any securities acquired directly from the Company or any of its affiliates other than in connection with the acquisition by the Company or any of its affiliates of a business) representing 20% or more of the combined voting power of the Company's then outstanding securities; or
 
(iv)          the stockholders of the Company approve a plan of complete liquidation or dissolution of the Company or there is consummated an agreement for the sale, disposition, lease or exchange by the Company of all or substantially all of the Company's assets, other than a sale, disposition, lease or exchange by the Company of all or substantially all of the Company's assets to an entity, at least 50% of the combined voting power of the voting securities of which are owned by stockholders of the Company in substantially the same proportions as their ownership of the Company immediately prior to such sale.
 
Notwithstanding the foregoing, a "Corporate Change" shall not be deemed to have occurred by virtue of the consummation of any transaction or series of integrated transactions immediately following which the record holders of the Common Stock of the Company immediately prior to such transaction or series of transactions continue to have substantially the same proportionate ownership in an entity which owns all or substantially all of the assets of the Company immediately following such transaction or series of transactions.
 
 
  2  

 
 
(k)   "Corporate Change Effective Date" shall mean:
 
(i)            the first date that the direct or indirect ownership of 20% or more combined voting power of the Company's outstanding securities results in a Corporate Change as described in clause (i) of such definition above; or
 
(ii)           the date of the election of Directors that results in a Corporate Change as described in clause (ii) of such definition; or
 
(iii)          the date of the merger or consideration that results in a Corporate Change as described in clause (iii) of such definition; or
 
(iv)          the date of stockholder approval that results in a Corporate Change as described in clause (iv) of such definition.
 
(l)   "Exchange Act" means the Securities Exchange Act of 1934, as amended.
 
(m)         "Fair Market Value" means, as of any specified date, the closing price of the Common Stock on the New York Stock Exchange (or, if the Common Stock is not then listed on such exchange, such other national securities exchange on which the Common Stock is then listed) on that date, or if no prices are reported on that date, on the last preceding date on which such prices of the Common Stock are so reported or, in the sole discretion of the Committee for purposes of determining the Fair Market Value of the Common Stock at the time of exercise of an Option or a Stock Appreciation Right, such Fair Market Value shall be the prevailing price of the Common Stock as of the time of exercise. If the Common Stock is not then listed or quoted on any national securities exchange but is traded over the counter at the time a determination of its Fair Market Value is required to be made hereunder, its Fair Market Value shall be deemed to be equal to the average between the reported high and low sales prices of Common Stock on the most recent date on which Common Stock was publicly traded. If the Common Stock is not publicly traded at the time a determination of its value is required to be made hereunder, the determination of its Fair Market Value shall be made by the Committee in such manner as it deems appropriate.
 
(n)   "Holder" means an employee or Non-employee Director of the Company who has been granted an Award.
 
(o)           "Immediate Family" means, with respect to a particular Holder, the Holder's spouse, parent, brother, sister, children and grandchildren (including adopted and step children and grandchildren).
 
(p)   "Incentive Stock Option" means an Option within the meaning of Section 422 of the Code.
 
(q)   "Minimum Criteria" shall have the meaning given such term in Paragraph (a) of Article IX.
 
(r)   "Non-employee Director" means a member of the Board who is not an employee or former employee of the Company or its Subsidiaries.
 
(s)           "Option" means an Award granted under Article VII of the Plan and includes both Incentive Stock Options to purchase Common Stock and Options which do not constitute Incentive Stock Options to purchase Common Stock.
 
(t)   "Option Agreement" means a written agreement between the Company and a Holder with respect to an Option.
 
(u)   "Optionee" means a Holder who has been granted an Option.
 
 
 
                                                                                                        3 

 
 
(v)   "Parent Corporation" shall have the meaning set forth in Section 424(e) of the Code.
 
(w)   "Performance Award" means an Award granted under Article X of the Plan.
 
(x)           "Person" shall have the meaning given in Section 3(a)(9) of the Exchange Act, as modified and used in Sections 13(d) and 14(d) thereof, except that such term shall not include (i) the Company or any of its Subsidiaries, (ii) a trustee or other fiduciary holding securities under an employee benefit plan of the Company or any of its affiliates, (iii) an underwriter temporarily holding securities pursuant to an offering of such securities, or (iv) a corporation owned, directly or indirectly, by the stockholders of the Company in substantially the same proportions as their ownership of stock of the Company.
 
(y)   "Plan" means the Halliburton Company 1993 Stock and Incentive Plan.
 
(z)   "Restricted Stock Award" means an Award granted under Article IX of the Plan.
 
(aa)         "Restricted Stock Award Agreement" means a written agreement between the Company and a Holder with respect to a Restricted Stock Award.
 
(bb)        "Restriction Period" shall have the meaning given such term in Paragraph (a) of Article IX.
 
(cc)         "Spread" means, in the case of a Stock Appreciation Right, an amount equal to the excess, if any, of the Fair Market Value of a share of Common Stock on the date such right is exercised over the exercise price of such Stock Appreciation Right.
 
(dd)         "Stock Appreciation Right" means an Award granted under Article VIII of the Plan.
 
(ee)         "Stock Appreciation Rights Agreement" means a written agreement between the Company and a Holder with respect to an Award of Stock Appreciation Rights.
 
(ff)   "Stock Value Equivalent Award" means an Award granted under Article XI of the Plan.
 
(gg)        "Subsidiary" means a company (whether a corporation, partnership, joint venture or other form of entity) in which the Company or a corporation in which the Company owns a majority of the shares of capital stock, directly or indirectly, owns a greater than 20% equity interest, except that with respect to the issuance of Incentive Stock Options the term "Subsidiary" shall have the same meaning as the term "subsidiary corporation" as defined in Section 424(f) of the Code.
 
(hh)        "Successor Holder" shall have the meaning given such term in Paragraph (f) of Article XIV.
 
III.   EFFECTIVE DATE AND DURATION OF THE PLAN
 
The Plan as amended and restated herein shall be effective February 12, 2003, the date of its adoption by the Board, provided the Plan is approved by the stockholders of the Company within twelve (12) months thereafter and on or prior to the date of the first annual meeting of stockholders of the Company held thereafter. Notwithstanding any provision of the Plan or in any Option Agreement or Stock Appreciation Rights Agreement, no Option or Stock Appreciation Right granted on or after February 12, 2003, shall be exercisable prior to such stockholder approval. Subject to the provisions of Article XIII, the Plan shall remain in effect until all Options and Stock Appreciation Rights granted under the Plan have been exercised or expired by reason of lapse of time, all restrictions imposed upon Restricted Stock Awards have lapsed and all Performance Awards and Stock Value Equivalent Awar ds have been satisfied; provided, however, that, notwithstanding any other provision of the Plan, Awards shall not be granted under the Plan after May 20, 2013.
 
 
  4  

 
 
IV.      ADMINISTRATION
 
(a)           Composition of Committee. The Plan shall be administered by a Committee of Directors of the Company which shall be appointed by the Board.
 
(b)           Powers. The Committee shall have authority, in its discretion, to determine which eligible individuals shall receive an Award, the time or times when such Award shall be made, whether an Incentive Stock Option, nonqualified Option or Stock Appreciation Right shall be granted, the number of shares of Common Stock which may be issued under each Option, Stock Appreciation Right and Restricted Stock Award, and the value of each Performance Award and Stock Value Equivalent Award. The Committee shall have the authority, in its discretion, to establish the terms and conditions applicable to any Award, subject to any specific limitations or provisions of the Plan. In making such determinations the Committee may take into account the nature of the services rendered by the respective individuals, their resp onsibility level, their present and potential contribution to the Company's success and such other factors as the Committee in its discretion shall deem relevant.
 
(c)   Additional Powers. The Committee shall have such additional powers as are delegated to it by the other provisions of the Plan. Subject to the express provisions of the Plan, the Committee is authorized to construe the Plan and the respective Award Documents executed thereunder, to prescribe such rules and regulations relating to the Plan as it may deem advisable to carry out the Plan, and to determine the terms, restrictions and provisions of each Award, including such terms, restrictions and provisions as shall be requisite in the judgment of the Committee to cause designated Options to qualify as Incentive Stock Options, and to make all other determinations necessary or advisable for administering the Plan. The Committee may correct any defect or supply any omission or reconcile any inconsisten cy in any Award Document relating to an Award in the manner and to the extent the Committee shall deem expedient to carry the Award into effect. The determinations of the Committee on the matters referred to in this Article IV shall be conclusive.
 
(d)           Delegation of Authority. The Committee may delegate some or all of its power to the Chief Executive Officer of the Company as the Committee deems appropriate; provided, however, that (i) the Committee may not delegate its power with regard to the grant of an Award to any person who is a "covered employee" within the meaning of Section 162(m) of the Code or who, in the Committee's judgment, is likely to be a covered employee at any time during the period an Award to such employee would be outstanding; (ii) the Committee may not delegate its power with regard to the selection for participation in the Plan of an officer or other person subject to Section 16 of the Exchange Act or decisions concerning the timing, pricing or amount of an Award to such an officer or other person and (iii) any delegation of the power to grant Awards shall be permitted by applicable law.
 
V. GRANT OF OPTIONS, STOCK APPRECIATION RIGHTS, RESTRICTED STOCK
AWARDS, PERFORMANCE AWARDS AND STOCK VALUE EQUIVALENT
AWARDS; SHARES SUBJECT TO THE PLAN
 
(a)   Award Limits. The Committee may from time to time grant Awards to one or more individuals determined by it to be eligible for participation in the Plan in accordance with the provisions of Article VI. The aggregate number of shares of Common Stock that may be issued under the Plan shall not exceed 49,000,000 shares, of which no more than 16,000,000 may be issued in the form of Restricted Stock Awards or pursuant to Performance Awards. Notwithstanding anything contained herein to the contrary, the number of Option shares or Stock Appreciation Rights, singly or in combination, together with shares or share equivalents under Performance Awards granted to any Holder in any one calendar year, shall not in the aggregate exceed 500,000. The cash value determined as of the date of grant of any Performanc e Award not denominated in Common Stock granted to any Holder for any one calendar year shall not exceed $5,000,000.  Any shares which remain
 
 
  5  

 
 
               unissued and which are not subject to outstanding Options or Awards at the termination of the Plan shall cease to be subject to the Plan, but, until termination of the Plan, the Company shall at all times reserve a sufficient number of shares to meet the requirements of the Plan. Shares shall be deemed to have been issued under the Plan only to the extent actually issued and delivered pursuant to an Award. To the extent that an Award lapses or the rights of its Holder terminate or the Award is paid in cash, any shares of Common Stock subject to such Award shall again be available for the grant of an Award. The aggregate number of shares which may be issued under the Plan shall be subject to adjustment in the same manner as provided in Article XII with respect to shares of Common Stock subjec t to Options then outstanding. The 500,000-share limit on Stock Options and Stock Appreciation Rights Awards to a Holder in any calendar year shall be subject to adjustment in the same manner as provided in Article XII. Separate stock certificates shall be issued by the Company for those shares acquired pursuant to the exercise of an Incentive Stock Option and for those shares acquired pursuant to the exercise of any Option which does not constitute an Incentive Stock Option. The Committee may from time to time adopt and observe such procedures concerning the counting of shares against the Plan maximum as it may deem appropriate.
 
(b)   Stock Offered. The stock to be offered pursuant to the grant of an Award may be authorized but unissued Common Stock or Common Stock previously issued and reacquired by the Company.
 
VI.   ELIGIBILITY
 
Awards made pursuant to the Plan may be granted to individuals who, at the time of grant, are employees of the Company or any Parent Corporation or Subsidiary of the Company or are Non-employee Directors. An Award may also be granted to a person who has agreed to become an employee of the Company or any Parent Corporation or Subsidiary of the Company within the subsequent three (3) months. An Award made pursuant to the Plan may be granted on more than one occasion to the same person, and such Award may include an Incentive Stock Option, an Option which is not an Incentive Stock Option, an Award of Stock Appreciation Rights, a Restricted Stock Award, a Performance Award, a Stock Value Equivalent Award or any combination thereof. Each Award shall be evidenced in such manner and form as may be prescribed by the Committee.
 
VII.   STOCK OPTIONS
 
(a)   Stock Option Agreement. Each Option shall be evidenced by an Option Agreement between the Company and the Optionee which shall contain such terms and conditions as may be approved by the Committee. The terms and conditions of the respective Option Agreements need not be identical. Specifically, an Option Agreement may provide for the payment of the option price, in whole or in part, by the delivery of a number of shares of Common Stock (plus cash if necessary) having a Fair Market Value equal to such option price.
 
(b)   Option Period. The term of each Option shall be as specified by the Committee at the date of grant; provided that, in no case, shall the term of an Option exceed ten (10) years.
 
(c)   Limitations on Exercise of Option. An Option shall be exercisable in whole or in such installments and at such times as determined by the Committee.
 
(d)   Option Price. The purchase price of Common Stock issued under each Option shall be determined by the Committee, but such purchase price shall not be less than the Fair Market Value of Common Stock subject to the Option on the date the Option is granted.
 
 
                                                                                                          6 

 
 
(e)   Options and Rights in Substitution for Stock Options Granted by Other Corporations. Options and Stock Appreciation Rights may be granted under the Plan from time to time in substitution for stock options held by employees of corporations who become, or who became prior to the effective date of the Plan, employees of the Company or of any Subsidiary as a result of a merger or consolidation of the employing corporation with the Company or such Subsidiary, or the acquisition by the Company or a Subsidiary of all or a portion of the assets of the employing corporation, or the acquisition by the Company or a Subsidiary of stock of the employing corporation with the result that such employing corporation becomes a Subsidiary.
 
(f)   Repricing Prohibited. Except for adjustments pursuant to Article XII, the purchase price of Common Stock for any outstanding Option granted under the Plan may not be decreased after the date of grant nor may an outstanding Option granted under the Plan be surrendered to the Company as consideration for the grant of a new Option with a lower purchase price. Any other action that is deemed to be a repricing under any applicable rule of the New York Stock Exchange shall be prohibited.
 
VIII.   STOCK APPRECIATION RIGHTS
 
(a)   Stock Appreciation Rights. A Stock Appreciation Right is the right to receive an amount equal to the Spread with respect to a share of Common Stock upon the exercise of such Stock Appreciation Right. Stock Appreciation Rights may be granted in connection with the grant of an Option, in which case the Option Agreement will provide that exercise of Stock Appreciation Rights will result in the surrender of the right to purchase the shares under the Option as to which the Stock Appreciation Rights were exercised. Alternatively, Stock Appreciation Rights may be granted independently of Options in which case each Award of Stock Appreciation Rights shall be evidenced by a Stock Appreciation Rights Agreement between the Company and the Holder which shall contain such terms and conditions as may be approv ed by the Committee. The terms and conditions of the respective Stock Appreciation Rights Agreements need not be identical. The Spread with respect to a Stock Appreciation Right may be payable either in cash, shares of Common Stock with a Fair Market Value equal to the Spread or in a combination of cash and shares of Common Stock. Upon the exercise of any Stock Appreciation Rights granted hereunder, the number of shares reserved for issuance under the Plan shall be reduced only to the extent that shares of Common Stock are actually issued in connection with the exercise of such Right.
 
(b)   Exercise Price. The exercise price of each Stock Appreciation Right shall be determined by the Committee, but such exercise price shall not be less than the Fair Market Value of a share of Common Stock on the date the Stock Appreciation Right is granted.
 
(c)   Exercise Period. The term of each Stock Appreciation Right shall be as specified by the Committee at the date of grant; provided that, in no case, shall the term of a Stock Appreciation Right exceed ten (10) years.
 
(d)   Limitations on Exercise of Stock Appreciation Right. A Stock Appreciation Right shall be exercisable in whole or in such installments and at such times as determined by the Committee.
 
(e)   Repricing Prohibited. Except for adjustments pursuant to Article XII, the exercise price of a Stock Appreciation Right may not be decreased after the date of grant nor may an outstanding Stock Appreciation Right granted under the Plan be surrendered to the Company as consideration for the grant of a new Stock Appreciation Right with a lower exercise price. Any other action that is deemed to be a repricing under any applicable rule of the New York Stock Exchange shall be prohibited.
 
 
  7  

 
 
IX.   RESTRICTED STOCK AWARDS
 
(a)   Restricted Period To Be Established by the Committee. At the time a Restricted Stock Award is made, the Committee shall establish a period of time (the "Restriction Period") applicable to such Award; provided, however, that, except as set forth below and as permitted by Paragraph (b) of this Article IX, such Restriction Period shall not be less than three (3) years from the date of grant (the "Minimum Criteria"). An award which provides for the lapse of restrictions on shares applicable to such Award in equal annual installments over a period of at least three (3) years from the date of grant shall be deemed to meet the Minimum Criteria. The foregoing notwithstanding, with respect to Restricted Stock Awards of up to an aggregate 550,000 shares (subject to adjustment as set forth in Article XII), the Minimum Criteria shall not apply and the Committee may establish such lesser Restriction Periods applicable to such Awards as it shall determine in its discretion. Subject to the foregoing, each Restricted Stock Award may have a different Restriction Period, in the discretion of the Committee. The Restriction Period applicable to a particular Restricted Stock Award shall not be changed except as permitted by Paragraph (b) of this Article or by Article XII.
 
(b)   Other Terms and Conditions. Common Stock awarded pursuant to a Restricted Stock Award shall be represented by a stock certificate registered in the name of the Holder of such Restricted Stock Award or, at the option of the Company, in the name of a nominee of the Company. The Holder shall have the right to receive dividends during the Restriction Period, to vote the Common Stock subject thereto and to enjoy all other stockholder rights, except that (i) the Holder shall not be entitled to possession of the stock certificate until the Restriction Period shall have expired, (ii) the Company shall retain custody of the stock during the Restriction Period, (iii) the Holder may not sell, transfer, pledge, exchange, hypothecate or otherwise dispose of the stock during the Restriction Period, and (iv) a breach of the terms and conditions established by the Committee pursuant to the Restricted Stock Award shall cause a forfeiture of the Restricted Stock Award. At the time of such Award, the Committee may, in its sole discretion, prescribe additional terms, conditions or restrictions relating to Restricted Stock Awards, including, but not limited to, rules pertaining to the termination of a Holder's service (by retirement, disability, death or otherwise) prior to expiration of the Restriction Period as shall be set forth in a Restricted Stock Award Agreement.
 
(c)   Payment for Restricted Stock. A Holder shall not be required to make any payment for Common Stock received pursuant to a Restricted Stock Award, except to the extent otherwise required by law and except that the Committee may, in its discretion, charge the Holder an amount in cash not in excess of the par value of the shares of Common Stock issued under the Plan to the Holder.
 
(d)   Miscellaneous. Nothing in this Article shall prohibit the exchange of shares issued under the Plan (whether or not then subject to a Restricted Stock Award) pursuant to a plan of reorganization for stock or securities in the Company or another corporation a party to the reorganization, but the stock or securities so received for shares then subject to the restrictions of a Restricted Stock Award shall become subject to the restrictions of such Restricted Stock Award. Any shares of stock received as a result of a stock split or stock dividend with respect to shares then subject to a Restricted Stock Award shall also become subject to the restrictions of the Restricted Stock Award.
 
X.   PERFORMANCE AWARDS
 
(a)   Performance Period. The Committee shall establish, with respect to and at the time of each Performance Award, a performance period over which the performance applicable to the Performance Award of the Holder shall be measured.
 
(b)   Performance Awards. Each Performance Award may have a maximum value established by the Committee at the time of such Award.
 
 
  8  

 
 
(c)   Performance Measures. A Performance Award granted under the Plan that is intended to qualify as qualified performance-based compensation under Section 162(m) of the Code shall be awarded contingent upon the achievement of one or more performance measures. The performance criteria for Performance Awards shall consist of objective tests based on the following: earnings, cash flow, cash value added performance, stockholder return and/or value, revenues, operating profits (including EBITDA), net profits, earnings per share, stock price, cost reduction goals, debt to capital ratio, financial return ratios, profit return and margins, market share, working capital and customer satisfaction. The Committee may select one criterion or multiple criteria for measuring performance. Performance criteria may be measured on corporate, subsidiary or business unit performance, or on a combination thereof. Further, the performance criteria may be based on comparative performance with other companies or other external measure of the selected performance criteria. A Performance Award that is not intended to qualify as qualified performance-based compensation under Section 162(m) of the Code shall be based on achievement of such goals and be subject to such terms, conditions and restrictions as the Committee or its delegate shall determine.
 
(d)   Payment. Following the end of the performance period, the Holder of a Performance Award shall be entitled to receive payment of an amount, not exceeding the maximum value of the Performance Award, if any, based on the achievement of the performance measures for such performance period, as determined by the Committee in its sole discretion. Payment of a Performance Award (i) may be made in cash, Common Stock or a combination thereof, as determined by the Committee in its sole discretion, (ii) shall be made in a lump sum or in installments as prescribed by the Committee in its sole discretion, and (iii) to the extent applicable, shall be based on the Fair Market Value of the Common Stock on the payment date. If a payment of cash or issuance of Common Stock is to be made on a deferred basis, the Com mittee shall establish whether interest or dividend equivalents shall be credited on the deferred amounts and any other terms and conditions applicable thereto.
 
(e)   Termination of Service. The Committee shall determine the effect of termination of service during the performance period on a Holder's Performance Award.
 
XI.   STOCK VALUE EQUIVALENT AWARDS
 
(a)   Stock Value Equivalent Awards. Stock Value Equivalent Awards are rights to receive an amount equal to the Fair Market Value of shares of Common Stock or rights to receive an amount equal to any appreciation or increase in the Fair Market Value of Common Stock over a specified period of time, which vest over a period of time as established by the Committee, without payment of any amounts by the Holder thereof (except to the extent otherwise required by law) or satisfaction of any performance criteria or objectives. Each Stock Value Equivalent Award may have a maximum value established by the Committee at the time of such Award.
 
(b)   Award Period. The Committee shall establish, with respect to and at the time of each Stock Value Equivalent Award, a period over which the Award shall vest with respect to the Holder.
 
(c)   Payment. Following the end of the determined period for a Stock Value Equivalent Award, the Holder of a Stock Value Equivalent Award shall be entitled to receive payment of an amount, not exceeding the maximum value of the Stock Value Equivalent Award, if any, based on the then vested value of the Award. Payment of a Stock Value Equivalent Award (i) shall be made in cash, (ii) shall be made in a lump sum or in installments as prescribed by the Committee in its sole discretion, and (iii) shall be based on the Fair Market Value of the Common Stock on the payment date. Cash dividend equivalents may be paid during, or may be accumulated and paid at the end of, the determined period with respect to a Stock Value Equivalent Award, as determined by the Committee. If payment of cash is to be made on a de ferred basis, the Committee shall establish whether interest shall be credited, the rate thereof and any other terms and conditions applicable thereto.
 
 
                                                                                                              9 

 
 
(d)   Termination of Service. The Committee shall determine the effect of termination of service during the applicable vesting period on a Holder's Stock Value Equivalent Award.
 
XII.   RECAPITALIZATION OR REORGANIZATION
 
(a)   Except as hereinafter otherwise provided, in the event of any recapitalization, reorganization, merger, consolidation, combination, exchange, stock dividend, stock split, extraordinary dividend or divestiture (including a spin-off) or any other change in the corporate structure or shares of Common Stock occurring after the date of the grant of an Award, the Committee shall, in its discretion, make such adjustment as to the number and price of shares of Common Stock or other consideration subject to such Awards as the Committee shall deem appropriate in order to prevent dilution or enlargement of rights of the Holders.
 
(b)   The existence of the Plan and the Awards granted hereunder shall not affect in any way the right or power of the Board or the stockholders of the Company to make or authorize any adjustment, recapitalization, reorganization or other change in the Company's capital structure or its business, any merger or consolidation of the Company, any issue of debt or equity securities having any priority or preference with respect to or affecting Common Stock or the rights thereof, the dissolution or liquidation of the Company or any sale, lease, exchange or other disposition of all or any part of its assets or business or any other corporate act or proceeding.
 
(c)   The shares with respect to which Options or Stock Appreciation Rights may be granted are shares of Common Stock as presently constituted, but if, and whenever, prior to the expiration of an Option or Stock Appreciation Rights, the Company shall effect a subdivision or consolidation of shares of Common Stock or the payment of a stock dividend on Common Stock without receipt of consideration by the Company, the number of shares of Common Stock with respect to which such Option or Stock Appreciation Rights may thereafter be exercised (i) in the event of an increase in the number of outstanding shares shall be proportionately increased, and the purchase price per share shall be proportionately reduced, and (ii) in the event of a reduction in the number of outstanding shares shall be proportionately r educed, and the purchase price per share shall be proportionately increased.
 
(d)   If the Company recapitalizes or otherwise changes its capital structure, thereafter upon any exercise of an Option or Stock Appreciation Rights theretofore granted, the Holder shall be entitled to purchase or receive, as applicable, under such Option or Stock Appreciation Rights, in lieu of the number of shares of Common Stock as to which such Option or Stock Appreciation Rights shall then be exercisable, the number and class of shares of stock and securities and the cash and other property to which the Holder would have been entitled pursuant to the terms of the recapitalization if, immediately prior to such recapitalization, the Holder had been the holder of record of the number of shares of Common Stock then covered by such Option or Stock Appreciation Rights.
 
(e)   In the event of a Corporate Change, unless an Award Document otherwise provides, as of the Corporate Change Effective Date (i) any outstanding Options and Stock Appreciation Rights shall become immediately vested and fully exercisable, (ii) any restrictions on Restricted Stock Awards shall immediately lapse, (iii) all performance measures upon which an outstanding Performance Award is contingent shall be deemed achieved and the Holder shall receive a payment equal to the maximum amount of the Award he or she would have been entitled to receive, prorated to the Corporate Change Effective Date, and (iv) any outstanding cash Awards including, but not limited to, Stock Value Equivalent Awards shall immediately vest and be paid based on the vested value of the Award.
 
 
  10  

 
 
(f)   In the relevant Award Document, the Committee may provide that, no later than two (2) business days prior to any Corporate Change referenced in Clause (ii), (iii) or (iv) of the definition thereof or ten (10) business days after any Corporate Change referenced in Clause (i) of the definition thereof, the Committee may, in its sole discretion, (i) require the mandatory surrender to the Company by selected Optionees of some or all of the outstanding Options held by such Optionees (irrespective of whether such Options are then exercisable under the provisions of the Plan) as of a date (before or after a Corporate Change) specified by the Committee, in which event the Committee shall thereupon cancel such Options and pay to each Optionee an amount of cash per share equal to the excess, if any, of the Change of Control Value of the shares subject to such Option over the exercise price(s) under such Options for such shares, (ii) require the mandatory surrender to the Company by selected Holders of Stock Appreciation Rights of some or all of the outstanding Stock Appreciation Rights held by such Holders (irrespective of whether such Stock Appreciation Rights are then exercisable under the provisions of the Plan) as of a date (before or after a Corporate Change) specified by the Committee, in which event the Committee shall thereupon cancel such Stock Appreciation Rights and pay to each Holder an amount of cash equal to the Spread with respect to such Stock Appreciation Rights with the Fair Market Value of the Common Stock at such time to be deemed to be the Change of Control Value, or (iii) require the mandatory surrender to the Company by selected Holders of Restricted Stock Awards or Performance Awards of some or all of the outstanding Awards held by such Holder (irrespective of whether such Awards are v ested under the provisions of the Plan) as of a date (before or after a Corporate Change) specified by the Committee, in which event the Committee shall thereupon cancel such Awards and pay to each Holder an amount of cash equal to the Change of Control Value of the shares, if the Award is denominated in Common Stock, or an amount of cash equal to the Fair Market Value of the Common Stock at such time, if the Award is not denominated in Common Stock.
 
(g)   Except as hereinbefore expressly provided, the issuance by the Company of shares of stock of any class or securities convertible into shares of stock of any class, for cash, property, labor or services, upon direct sale, upon the exercise of rights or warrants to subscribe therefor, or upon conversion of shares or obligations of the Company convertible into such shares or other securities, and in any case whether or not for fair value, shall not affect, and no adjustment by reason thereof shall be made with respect to, the number of shares of Common Stock subject to Options or Stock Appreciation Rights theretofore granted, the purchase price per share of Common Stock subject to Options or the calculation of the Spread with respect to Stock Appreciation Rights.
 
XIII.   AMENDMENT OR TERMINATION OF THE PLAN
 
The Board in its discretion may terminate the Plan or alter or amend the Plan or any part thereof from time to time; provided that no change in any Award theretofore granted may be made which would impair the rights of the Holder without the consent of the Holder, and provided, further, that the Board may not, without approval of the stockholders, amend the Plan to effect a "material revision" of the Plan, where a "material revision" includes, but is not limited to, a revision that: (a) materially increases the benefits accruing to a Holder under the Plan, (b) materially increases the aggregate number of securities that may be issued under the Plan, (c) materially modifies the requirements as to eligibility for participation in the Plan, (d) changes the types of awards available under the Plan, or (e) amends or deletes the provisions that prevent the Committee from amending the term s and conditions of an outstanding Option or Stock Appreciation Rights to alter the exercise price.
 
XIV.   OTHER
 
(a)   No Right To An Award. Neither the adoption of the Plan nor any action of the Board or of the Committee shall be deemed to give an employee or a non-employee Director any right to be granted an Option, a Stock Appreciation Right, a right to a Restricted Stock Award or a right to a Performance Award or Stock Value Equivalent Award or any other rights hereunder except as may be evidenced by an Award or by an Option or Stock Appreciation Agreement duly executed on behalf of the Company, and then only to the extent of and on the terms and conditions expressly set forth therein. The Plan shall be unfunded. The Company shall not be required to establish any special or separate fund or to make any other segregation of funds or assets to assure the payment of any Award.
 
 
  11  

 
 
(b)   No Employment Rights Conferred. Nothing contained in the Plan or in any Award made hereunder shall:
 
(i)   confer upon any employee any right to continuation of employment with the Company or any Subsidiary; or
 
(ii)   interfere in any way with the right of the Company or any Subsidiary to terminate his or her employment at any time.
 
(c)   No Rights to Serve as a Director Conferred. Nothing contained in the Plan or in any Award made hereunder shall confer upon any Director any right to continue their position as a Director of the Company.
 
(d)   Other Laws; Withholding. The Company shall not be obligated to issue any Common Stock pursuant to any Award granted under the Plan at any time when the offering of the shares covered by such Award has not been registered under the Securities Act of 1933 and such other state and federal laws, rules or regulations as the Company or the Committee deems applicable and, in the opinion of legal counsel for the Company, there is no exemption from the registration requirements of such laws, rules or regulations available for the issuance and sale of such shares. No fractional shares of Common Stock shall be delivered, nor shall any cash in lieu of fractional shares be paid. The Company shall have the right to deduct in connection with all Awards any taxes required by law to be withheld and to require any payments necessary to enable it to satisfy its withholding obligations. The Committee may permit the Holder of an Award to elect to surrender, or authorize the Company to withhold, shares of Common Stock (valued at their Fair Market Value on the date of surrender or withholding of such shares) in satisfaction of the Company's withholding obligation, subject to such restrictions as the Committee deems appropriate.
 
(e)   No Restriction on Corporate Action. Nothing contained in the Plan shall be construed to prevent the Company or any Subsidiary from taking any corporate action which is deemed by the Company or such Subsidiary to be appropriate or in its best interest, whether or not such action would have an adverse effect on the Plan or any Award made under the Plan. No Holder, beneficiary or other person shall have any claim against the Company or any Subsidiary as a result of any such action.
 
(f)   Restrictions on Transfer. Except as otherwise provided herein, an Award shall not be sold, transferred, pledged, assigned or otherwise alienated or hypothecated by a Holder other than by will or the laws of descent and distribution or pursuant to a "qualified domestic relations order" as defined by the Code or Title I of the Employee Retirement Income Security Act of 1974, as amended, and shall be exercisable during the lifetime of the Holder only by such Holder, the Holder's guardian or legal representative, a transferee under a qualified domestic relations order or a transferee as described below. The Committee may prescribe and include in the respective Award Documents hereunder other restrictions on transfer. Any attempted assignment or transfer in violation of this section shall be null and void. Upon a Holder's death, the Holder's personal representative or other person entitled to succeed to the rights of the Holder (the "Successor Holder") may exercise such rights as are provided under the applicable Award Document. A Successor Holder must furnish proof satisfactory to the Company of his or her rights to exercise the Award under the Holder's will or under the applicable laws of descent and distribution. Notwithstanding the foregoing, the Committee shall have the authority, in its discretion, to grant  (or to sanction by way  of amendment  to an existing grant)  Awards (other than Incentive Stock Options)  which may
 
 
                                                                                                          12 

 
 
               be transferred by the Holder for no consideration to or for the benefit of the Holder's Immediate Family, to a trust solely for the benefit of the Holder and his Immediate Family, or to a partnership or limited liability company in which the Holder and members of his Immediate Family have at least 99% of the equity, profit and loss interest, in which case the Award Document shall so state. A transfer of an Award pursuant to this Paragraph (f) shall be subject to such rules and procedures as the Committee may establish. In the event an Award is transferred as contemplated in this Paragraph (f), such Award may not be subsequently transferred by the transferee except by will or the laws of descent and distribution, and such Award shall continue to be governed by and subject to the terms and limitati ons of the Plan and the relevant written instrument for the Award and the transferee shall be entitled to the same rights as the Holder under Articles XII and XIII hereof as if no transfer had taken place. No transfer shall be effective unless and until written notice of such transfer is provided to the Committee, in the form and manner prescribed by the Committee. The consequences of termination of employment shall continue to be applied with respect to the original Holder, following which the Awards shall be exercised by the transferee only to the extent and for the periods specified in the Plan and the related Award Document. The Option Agreement, Stock Appreciation Rights Agreement, Restricted Stock Agreement or other Award Document shall specify the effect of the death of the Holder on the Award.
 
(g)           Governing Law. This Plan shall be construed in accordance with the laws of the State of Texas, except to the extent that it implicates matters which are the subject of the General Corporation Law of the State of Delaware which matters shall be governed by the latter law.
 
(h)          Foreign Awardees. Without amending the Plan, the Committee may grant Awards to eligible persons who are foreign nationals on such terms and conditions different from those specified in the Plan as may, in the judgment of the Committee, be necessary or desirable to foster and promote achievement of the purposes of the Plan and, in furtherance of such purposes, the Committee may make such modifications, amendments, procedures, subplans and the like as may be necessary or advisable to comply with the provisions of laws and regulations in other countries or jurisdictions in which the Company or its Subsidiaries operate.
 
 
 
  13   
 
 
Unassociated Document

                                                                    Exhibit 12

HALLIBURTON COMPANY
Computation of Ratio of Earnings to Fixed Charges
(Unaudited)
(Millions of dollars, except for ratios)

 
 
 
     
Six Months
Ended
Year Ended December 31

 
 
June 2004
2003
2002
2001
2000
1999

 
Earnings available for fixed charges:
   
 
   
 
   
 
   
 
   
 
   
 
 
Income (loss) from continuing
   
 
   
 
   
 
   
 
   
 
   
 
 
operations before income taxes,
   
 
   
 
   
 
   
 
   
 
   
 
 
minority interests, and
   
 
   
 
   
 
   
 
   
 
   
 
 
cumulative effects of accounting
   
 
   
 
   
 
   
 
   
 
   
 
 
changes, net
 
$
51
 
$
612
 
$
(228
)
$
954
 
$
335
 
$
307
 
Add:
   
 
   
 
   
 
   
 
   
 
   
 
 
   Distributed earnings from
   
 
   
 
   
 
   
 
   
 
   
 
 
       equity in unconsolidated
   
 
   
 
   
 
   
 
   
 
   
 
 
       affiliates
   
12
   
97
   
19
   
25
   
27
   
57
 
   Fixed charges
   
141
   
203
   
168
   
209
   
203
   
194
 

 
           Subtotal
   
204
   
912
   
(41
)
 
1,188
   
565
   
558
 
Less:
   
 
   
 
   
 
   
 
   
 
   
 
 
   Undistributed equity in
   
 
   
 
   
 
   
 
   
 
   
 
 
       earnings and losses of
   
 
   
 
   
 
   
 
   
 
   
 
 
       unconsolidated affiliates
   
(15
)
 
25
   
74
   
107
   
88
   
99
 

 
           Total
 
$
219
 
$
887
 
$
(115
)
$
1,081
 
$
477
 
$
459
 

 
Fixed charges:
   
 
   
 
   
 
   
 
   
 
   
 
 
Interest expense
 
$
109
 
$
139
 
$
113
 
$
147
 
$
146
 
$
141
 
Rental expense representative
   
 
   
 
   
 
   
 
   
 
   
 
 
   of interest
   
32
   
64
   
55
   
62
   
57
   
53
 

 
           Total
 
$
141
 
$
203
 
$
168
 
$
209
 
$
203
 
$
194
 

 
 
   
 
   
 
   
 
   
 
   
 
   
 
 
Ratio of earnings to fixed charges
   
1.6
   
4.4
   
(a
)
 
5.2
   
2.3
   
2.4
 

 

(a) For the year ended December 31, 2002, earnings were inadequate to cover fixed charges by $283 million.
Unassociated Document


 
Exhibit 31.1

SECTION 302 CERTIFICATION
 
I, David J. Lesar, certify that:
 
    1.     I have reviewed this quarterly report on Form 10-Q for the quarter ending June 30, 2004 of Halliburton Company;
 
    2.     Based on my knowledge, this report does not contain any untrue statement of a material fact or omit to state a material fact necessary to make the statements made, in light of the circumstances under which such statements were made, not misleading with respect to the period covered by this report;
 
    3.     Based on my knowledge, the financial statements, and other financial information included in this report, fairly present in all material respects the financial condition, results of operations and cash flows of the registrant as of, and for, the periods presented in this report;
 
    4.     The registrant's other certifying officer(s) and I are responsible for establishing and maintaining disclosure controls and procedures (as defined in Exchange Act Rules 13a-15(e) and 15d-15(e)) for the registrant and have:
 
    (a)    Designed such disclosure controls and procedures, or caused such disclosure controls and procedures to be designed under our supervision, to ensure that material information relating to the registrant, including its consolidated subsidiaries, is made known to us by others within those entities, particularly during the period in which this report is being prepared;
 
    (b)   Evaluated the effectiveness of the registrant's disclosure controls and procedures and presented in this report our conclusions about the effectiveness of the disclosure controls and procedures, as of the end of the period covered by this report based on such evaluation; and
 
    (c)   Disclosed in this report any change in the registrant's internal control over financial reporting that occurred during the registrant's most recent fiscal quarter (the registrant's fourth fiscal quarter in the case of an annual report) that has materially affected, or is reasonably likely to materially affect, the registrant's internal control over financial reporting; and
 
     

 
    5.    The registrant's other certifying officer(s) and I have disclosed, based on our most recent evaluation of internal control over financial reporting, to the registrant's auditors and the audit committee of the registrant's board of directors (or persons performing the equivalent functions):
 
    (a)   All significant deficiencies and material weaknesses in the design or operation of internal control over financial reporting which are reasonably likely to adversely affect the registrant's ability to record, process, summarize and report financial information; and
 
    (b)   Any fraud, whether or not material, that involves management or other employees who have a significant role in the registrant's internal control over financial reporting.
 

 
Date:   August 3, 2004
 
/s/ David J. Lesar

 
David J. Lesar
 
Chief Executive Officer


     
Unassociated Document

 

Exhibit 31.2
 
 
SECION 302 CERTIFICATION
 
I, C. Christopher Gaut, certify that:
 
    1.          I have reviewed this quarterly report on Form 10-Q for the quarter ending June 30, 2004 of Halliburton Company;
 
    2.           Based on my knowledge, this report does not contain any untrue statement of a material fact or omit to state a material fact necessary to make the statements made, in light of the circumstances under which such statements were made, not misleading with respect to the period covered by this report;
 
    3.           Based on my knowledge, the financial statements, and other financial information included in this report, fairly present in all material respects the financial condition, results of operations and cash flows of the registrant as of, and for, the periods presented in this report;
 
    4.          The registrant's other certifying officer(s) and I are responsible for establishing and maintaining disclosure controls and procedures (as defined in Exchange Act Rules 13a-15(e) and 15d-15(e)) for the registrant and have:
 
         (a)    Designed such disclosure controls and procedures, or caused such disclosure controls and procedures to be designed under our supervision, to ensure that material information relating to the registrant, including its consolidated subsidiaries, is made known to us by others within those entities, particularly during the period in which this report is being prepared;
 
         (b)    Evaluated the effectiveness of the registrant's disclosure controls and procedures and presented in this report our conclusions about the effectiveness of the disclosure controls and procedures, as of the end of the period covered by this report based on such evaluation; and
 
         (c)   Disclosed in this report any change in the registrant's internal control over financial reporting that occurred during the registrant's most recent fiscal quarter (the registrant's fourth fiscal quarter in the case of an annual report) that has materially affected, or is reasonably likely to materially affect, the registrant's internal control over financial reporting; and
 
 
     

 
 
    5.    The registrant's other certifying officer(s) and I have disclosed, based on our most recent evaluation of internal control over financial reporting, to the registrant's auditors and the audit committee of the registrant's board of directors (or persons performing the equivalent functions):
 
          (a)  All significant deficiencies and material weaknesses in the design or operation of internal control over financial reporting which are reasonably likely to adversely affect the registrant's ability to record, process, summarize and report financial information; and
 
          (b)    Any fraud, whether or not material, that involves management or other employees who have a significant role in the registrant's internal control over financial reporting.


Date:   August 3, 2004
 
/s/ C. Christopher Gaut

C. Christopher Gaut
 
Chief Financial Officer


     
Unassociated Document

 

Exhibit 32.1



CERTIFICATION PURSUANT TO
18 U.S.C. SECTION 1350
AS ADOPTED PURSUANT TO
SECTION 906 OF THE SARBANES-OXLEY ACT OF 2002


In connection with the Quarterly Report of Halliburton Company (the “Company”) on Form 10-Q for the period ending June 30, 2004 as filed with the Securities and Exchange Commission on the date hereof (the “Report”), I, David J. Lesar, Chief Executive Officer of the Company, certify, pursuant to 18 U.S.C. § 1350, as adopted pursuant to § 906 of the Sarbanes-Oxley Act of 2002, that:

    (1)   The Report fully complies with the requirements of section 13(a) or 15(d) of the Securities Act of 1934; and

    (2)   The information contained in the Report fairly presents, in all material respects, the financial condition and results of operations of the Company.



/s/ David J. Lesar
David J. Lesar
Chief Executive Officer
Date:     August 3, 2004

Unassociated Document

 

Exhibit 32.2



CERTIFICATION PURSUANT TO
18 U.S.C. SECTION 1350
AS ADOPTED PURSUANT TO
SECTION 906 OF THE SARBANES-OXLEY ACT OF 2002



In connection with the Quarterly Report of Halliburton Company (the “Company”) on Form 10-Q for the period ending June 30, 2004 as filed with the Securities and Exchange Commission on the date hereof (the “Report”), I, C. Christopher Gaut, Chief Financial Officer of the Company, certify, pursuant to 18 U.S.C. § 1350, as adopted pursuant to § 906 of the Sarbanes-Oxley Act of 2002, that:

    (1)   The Report fully complies with the requirements of section 13(a) or 15(d) of the Securities Act of 1934; and

    (2)   The information contained in the Report fairly presents, in all material respects, the financial condition and results of operations of the Company.


/s/ C. Christopher Gaut
C. Christopher Gaut
Chief Financial Officer
Date:  August 3, 2004